Julian Street Inn – Shelter for the Homeless
1986 to 1990
Julian St. & Montgomery St., San Jose, CA, U.S.A.
Civic, Realized
, Construction completed in 1989; final interior painting in 1990
Design and construction of a shelter for homeless people, to serve 50 to 100 people, on a site of 13,000 sf. The building of 15,000 square feet includes offices, living areas with a dining hall, sleeping rooms, courtyards and gardens. The design gave emphasis on the dignity of the homeless people, and the effort to give them a "home". Building was designed with major participation of the clients and members of the homeless community. Concrete columns and beams, open lacework trusses, heavy timber beams and ceiling, interiors plaster, exterior terracotta tiles with glazed green inserts, and decorative tiles.
Client:
Housing for Independent People - Al DiLudovico, Executive Director
C.E.S. staff:
Christopher Alexander, Gary Black, Artemis Anninou, Carl Lindberg, James Maguire, Eleni Coromvli, Kleoniki Tsotropoulou
Contractor:
Oliver and Company, with Center for Environmetal Structure as major specialty subcontractor
Project cost:
$1,700,000
Project stages:
Pattern language for project by clients and C.E.S.
Layout by clients and C.E.S.
Use of full scale mock-ups
Design Development and Building Permit drawings
Direct Construction management and on-site design decisions
Budget and subcontractors under C.E
Contents
-
Julian Street Inn - Shelter for the Homeless: Exterior wall made of repetitive recessed bays framed by massive columns
1987
Building Detail, Wall TreatmentCreated by:Christopher Alexander, Gary Black, Carl Lindberg, James MaguireA long wall along the main street; the first floor wall is organized as an alternating repetition of cast concrete columns and plain recessed wall bays, all on a thick wall base, in contrast with the second floor wall, all ...
-
Julian Street Inn - Shelter for the Homeless: Column capitals with ornamental details
1987
Work of Art for Project, OrnamentCreated by:Christopher AlexanderHand-made cast-concrete column capitals with ornamental details, his mouth being the water flow hole.
-
Julian Street Inn - Shelter for the Homeless: Courtyard fountain with lion's head
1988
Work of Art for Project, OrnamentCreated by:Christopher Alexander, Robert M. WalshCast-concrete lion's head on the back wall of the tiled fountain located in the courtyard of the Julian Street Inn.
-
Julian Street Inn - Shelter for the Homeless: Lacework concrete trusses with curved members shot in the air
1988
Construction System, Sprayed ConcreteCreated by:Christopher Alexander, Gary Black, Carl Lindberg, Avery Miller, James MaguireThe dining hall of Julian street inn is the higher building volume of the complex; the hall, a sigle room, 30 feet wide and 50 feet long, was intended to seat about 100 people. When the shape of the volume ...
-
Julian Street Inn - Shelter for the Homeless: Exterior wall cladding with hand-painted and hand-glazed tilework
1988
Work of Art for Project, Hand-glazed TileworkCreated by:Christopher Alexander, Kleoniki Tsotropoulou4.500 hand-glazed grey tiles with hand-drawn geometric pattern, on reddish Mexican body tiles, for cladding the second floor exterior walls of the Julian Street Inn.
-
Julian Street Inn - Shelter for the Homeless: Construction experiments for testing the prefabrication of wall-segment tile panels and lifting them in place
1988
Construction System, Hand-glazed Tilework PanelCreated by:Christopher Alexander, Gary BlackSeries of experiments and tests performed in the C.E.S. workshop in Martinez, for prefabricating wall-segment panels flat on the ground with the hand-glazed tiles, the required reinforcement and concrete layer, and then testing the procedure of lifting them in place. ...
-
Julian Street Inn - Shelter for the Homeless: Courtyard fountain with hand-painted and hand-glazed tilework
1988
Work of Art for Project, Hand-glazed TileworkCreated by:Christopher Alexander, Kleoniki Tsotropoulou, Robert M. WalshTilework with diagonal squared pattern with four-petal flower in interchanging green and salmon, cladding the base wall of the fountain.
-
Julian Street Inn - Shelter for the Homeless: Dining hall interior color
1989
Work of Art for Project, Hand-painted InteriorCreated by:Christopher AlexanderChoosing the color for the dining hall and making mock-ups for testing accuracy of certain colors and patterns.
SEE ALL Construction Innovations
-
The Julian Street Inn - Shelter for the Homeless: Informing on the key aspects to be included in the design of the shelter which arose during a meeting with the client taking also under consideration concerns and desires of the users
02/08/1986
Design Matters, Minutes of MeetingSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Introducing their firm's qualifications for undertaking the construction process of the shelter as Christopher Alexander had requested from them
23/09/1986
Expression of Interest, InformativeSender:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Discusses the lack of a Uniform Building Code in reference to occupancy that is applicable to the Homeless Center, proposes various approximate code possibilities and expresses the need to further pursue the establishment of specifications for this case
12/08/1986
Design Matters, Response to RequestSender:Jim Lyle, Pacific Design Group, Campbell, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Providing an update on material for concrete casting, coloring, and concrete strength testing. Also mentions concrete inserts and other experiment samples
12/06/1988
Construction Works, NotificationSender:Matisse, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Gary Black, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Note
-
The Julian Street Inn - Shelter for the Homeless: Response to a request by Center for Environmental Structure to prepare a construction schedule according to the specifications of the project; with attached construction schedule
28/12/1987
Construction Works, ScheduleSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Gary Black, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Clarifying the importance of a steady project budget without fluctuations which would jeopardize its success. Laying out the details of specific amounts and forwarding a budget list as a means of better communication and understanding
03/04/1987
Financial, BudgetSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Request to provide supplemental documentation in the form of bills and ledgers for engineering, extra time and printing costs
28/07/1987
Financial, Outstanding IssuesSender:Celia, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Note
-
The Julian Street Inn - Shelter for the Homeless: Expressing great concerns and dissatisfaction about the way the financial arrangements and payments have been handled. An analysis of events is also described by seven major points, clarifying the reasons for this. Letter also mentions that a draft of specifications is attached to it
28/08/1987
Administrative, InformativeSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Summary of Clarifications and Qualifications to the contract between the general contractor and the Shelter for the Homeless. Included are lists of modifications, conditions and allowances incorporated to the contract's price, as well as items not included and the assumptions that are made about materials to be used. There is one more, earlier version of the letter
19/11/1987
Contractual, Construction ContractSender:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: A draft letter with a handwritten note requesting review by Christoper Alexander. Letter asks for approval of the foundation plan by the City Building Official and explains why other pending permits will not affect the proposed foundation design.
16/10/1987
Administrative, InformativeSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Fax
-
The Julian Street Inn - Shelter for the Homeless: Confirmation letter regarding the approval of the gas meter location by PG&E and requesting completion of final drawings
02/12/1987
Administrative, Outstanding IssuesSender:Linda M. Carlson, Pacific Gas and Electric Company, San Jose, CA, U.S.A.Recipient:Eleni Coromvli, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Bond - Transmittal of a 3-part Message & Reply form regarding the issuance of bond, and requesting the completion to the attached questionnaire and return with financial statements
10/08/1987
Administrative, TransmittalSender:Gordon W. Richards, R. C. Fischer & Co., Oakland, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Form
-
The Julian Street Inn - Shelter for the Homeless: Bond - Forwarding the certified statements of assets, liabilities and fund balance for the Center of Environmental Structure, Inc., together with the related statements of revenues and expenses as of 31-Dec-1984, 31-Dec-85, 31-Dec-86 (revised) and 31-Dec-86.
18/10/1987
Financial, TransmittalSender:Stieven Kliegman, Certified Public Accountant, Oakland, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Bond - Forwarding three pages with reference information on insurance and bonding requirements for construction of the Shelter for the Homeless.
19/05/1987
Administrative, TransmittalSender:Kristie Kesel Hatten, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Budget summary with items over the budget, future adds, and other potential adds
05/02/1988
Financial, InformativeSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Clarifying the specific responsibilities of the architect and distinguishing them from those of the contractor, regarding the provision of special constructing details
07/02/1988
Construction Works, Response to RequestSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Draft of a letter prepared in response to a meeting between Center for Environmental Structure and the contractor discussing the process to be followed by both in providing solutions to potential problem-areas; letter has been edited and returned
25/02/1988
Planning of Works, MemorandumSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Follow-up of a telephone conversation, discussing the issue of having to adjust the layout of the building on the site and the need to update drawings
02/03/1988
Planning of Works, Request for FeedbackSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Letter demanding corrections that must be made on the application for payment, "AIA G702A" form, submitted on 22-Mar-1988
28/03/1988
Financial, Transaction DocumentSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Billing Procedure for Housing for Independent People Project: Demanding regular, monthly statements of account to be submitted by the contractors to Center for Environmental Structure
28/03/1988
Financial, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Clarifications, Change Orders and Arbitration. Outlines of each included
28/03/1988
Contractual, Construction ContractSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Estimated Progress Schedule, with two points of request
28/03/1988
Planning of Works, ScheduleSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: (22-Mar-1988) Monthly Statement of Account. Asking for re-submittal of the statement as per the requirements described by Center for Environmental Structure in the 24-Mar-1988 letter
28/03/1988
Financial, Outstanding IssuesSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Efficient On-site Management: Requiring from the construction manager more flexibility and adaptation to small decisions needed to be made on site by the architect
28/03/1988
Construction Works, Construction ProcessSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Financial Management of Housing for Independent People Project. Informing the general contractor of the Center for Environmental Structure overseeing the financial management; attached is a detailed official listing of contract line items
08/04/1988
Contractual, InformativeSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Letter responding to varying previous requests including: 1. Application for payment form G702A; 2. Monthly statements of account; 3. Subcontracts; 4. Clarifications, change orders and arbitration, progress schedule; 5. Financial management, as well as bonding and insurance
12/04/1988
Construction Works, Response to RequestSender:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Gary Black, Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Informing Housing for Independent People that the Center for Environmental Structure approves only the payment of the attached bill, sent by Oliver & Company, but does not approve the actual values appearing on the schedule of values prepared by them. Values will be corrected by Center for Environmental Structure
28/04/1988
Financial, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Raising concerns regarding the schedule of values presented by Oliver & Company and letting them know that the Center for Environmental Structure will review and revise it. The company needs to re-send the certificate of payment for the Center for Environmental Structure to proceed with the payment of the approved bill
28/04/1988
Financial, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Request for completion of the fourteen clarification details, as previously discussed
13/06/1988
Design Matters, Request for FeedbackSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Response to request for clarification details
20/06/1988
Design Matters, Response to RequestSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Requesting completion of a) pending clarification details; b) revised structural details for changes proposed on 2nd floor walls; c) other miscellaneous issues
30/06/1988
Design Matters, Request for FeedbackSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding a "Final Schedule of Values" list for review and acceptance; to be used as guide for all future requests for payment
26/08/1988
Financial, NotificationSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Requiring an answer on the "Final Schedule of Values" previously sent; continued use of the temporary schedule of values is unacceptable
20/09/1988
Financial, Request for FeedbackSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Indication of receipt of schedule of values and informing on a request by the owner to apply 'Change Orders' in all future modifications in contract work
23/09/1988
Financial, Response to RequestSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Request for extension of contract due to the delays outlined in the letter
13/10/1988
Contractual, Request for FeedbackSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Discussion of issues preventing payment be made to Center for Environmental Structure and the resolutions required including obtaining insurance and bonding
21/11/1988
Contractual, Response to RequestSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Request for past due payment. Re-establishing previously ignored points regarding job responsibilities with inclusions and exclusions of responsibilities. Notes of the goodwill already provided
22/11/1988
Financial, Request for PaymentSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding the revised schedule of values after reviewing all factors like contracts, estimates and precontract negotiations. Requesting of the contractor to consider the values and prepare documents for further discussion as needed. Different line items included, are marked, and need further review
01/05/1988
Financial, Request for FeedbackSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Providing information on the nailing pattern to be followed for constructing the shear walls; with two sketches of wall details attached
30/09/1988
Design Matters, TransmittalSender:A. J. Miller, A. J. Miller & Associates, Structural Engineering Corporation, Berkeley, CA, U.S.A.Recipient:Paul Reudi, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Asking for the contractor's recommendations on waterproofing details for the exterior walls that would give a final solution to the problem. A statement of halting construction activities that affect directly this issue is also made
31/01/1988
Design Matters, Response to RequestSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Note
-
The Julian Street Inn - Shelter for the Homeless: Forwarding a design drawing for the installation of the water facilities for the project and a cost estimate for this job. Responsibilities for each party are outlined. Signed and acknowledged by Al DiLudovico
02/02/1988
Design Matters, NotificationSender:Wayne S. Warren, San Jose Water Company, San Jose, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Responding to the request for waterproofing recommendations and clarifying that the contractor is not qualified to make such recommendations as to such solutions. Also, expresses the need to have a definite statement as to when construction activities can be resumed
04/02/1988
Design Matters, Response to RequestSender:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Discusses design responsibilities vs. implementation of designs: Architects and engineers design and contractors install and build according to design. This letter specifically deals with building leak issues and where there is potential for problems. It is stated that Oliver & Company Inc. have every intention of making the building waterproof, but indeed they must utilize the drawings, specifications and details provided to them
18/02/1988
Design Matters, NotificationSender:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding a check for the installation of the water facilities for the project. Also, a limited encroachment to the southwest portion of the lot is granted for installing the water meter boxes
01/03/1988
Design Matters, Response to RequestSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Wayne S. Warren, San Jose Water Company, San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: San Jose Housing Project. Giving an update on 8 different aspects of the project and requesting the issuing of specific change orders and drawings regarding the proposed changes, which are also affecting the contract budget. Budget excesses to be included in the change orders
31/03/1988
Financial, Outstanding IssuesSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Gary Black, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Response after reviewing the final schedule of values proposed by Christopher Alexander and the Center for Environmental Structure on 8-Apr-1988. Suggestions are made
04/04/1988
Financial, Cost EstimateSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Gary Black, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Responding to a letter titled "Design Services Shelter for the Homeless" and commenting on five points regarding: costs of design fees, the proposed project management, additional management fees that are needing discussion, arbitrator costs and the proposed seven-day payment on the bills
05/04/1988
Financial, Outstanding IssuesSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Apologies for having to terminate a meeting scheduled to discuss multiple correspondence. A request to reschedule is made
07/04/1988
Financial, Outstanding IssuesSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Informing on the issue of project management by the architect in accordance with the contract and demanding that all future correspondence, inquiries, change order requests and bills be sent directly to the Center for Environmental Structure management, including any discussions relating to financial matters
08/04/1988
Contractual, NotificationSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding a list of the categories which should be included in the contractor's schedule of values
08/04/1988
Financial, Cost EstimateSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding two letters to the Center for Environmental Structure from: 1. the Allied Electric Company discussing issues encountered running the electric conduits in the slab; 2. the Lescure Company requesting immediate feedback back on the submitted drawings for the sprinkler system, to avoid project delays
22/04/1988
Design Matters, NotificationSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Fax
-
The Julian Street Inn - Shelter for the Homeless: Responding on the issues of 1. The men's shower drainage as having been discussed and solved; 2. The shop drawings for the heating system as having been sent for the architect's review; 3. The sprinkler system for the attic of the dining hall and must be discussed with the fire chief to verify whether the attic sprinklers are required or not. Once this determination is made, a determination as to their positioning will be made
15/04/1988
Design Matters, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Confirming the discussed upon points during two different telephone conversations relating to modifications of a specific payment application
22/04/1988
Financial, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Demand for payment of an already overdue bill. The delay of payment is breaking a given promise for timely payments. If this request is not answered, then Center for Environmental Structure will withdraw its project manager. One more bill is attached
25/04/1988
Financial, NotificationSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Notification that three pieces of information must be provided before PG&E engineering and service can be established: 1) site plan, 2) construction schedule and 3) Load Data Sheet. Service is threatened to be behind schedule
25/04/1988
Progress of Works, NotificationSender:Linda M. Carlson, Pacific Gas and Electric Company, San Jose, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Addressing the issues encountered in relation to electrical installations in the walls, caused by difficulties in interpreting the provided drawings. This problem should have been communicated directly to the project manager on time otherwise the architect could not be held responsible. The same timeliness is demanded for any other problem encountered by the superintendent or a subcontractor in the future
25/04/1988
Construction Works, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Responding on the issue of modifying the placement of the sprinkler system for the dining hall. Shop drawings illustrating the architect's layout have already been approved regarding aesthetic design only, and no additional costs are involved
25/04/1988
Construction Works, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Scheduled meeting between Steve Oliver, Maxim Schrogin, Christopher Alexander, Gary Black, Henry Sterngold. Agenda is attached with seven topics to be addressed
10/05/1988
Planning of Works, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Providing an overview of the 12-May-1988 meeting and laying out some of the specific issues discussed and approved by both, the architect, and the contractor
13/05/1988
Administrative, Minutes of MeetingSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Updating, after a visit to the job site, on issues requiring immediate responses. Issues are relating to: finish hardware, door specifications, location of electrical supply, construction type of the dining room foundation wall, and window designs
16/05/1988
Planning of Works, NotificationSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Reminding Maxim Schrogin that the electrical, plumbing and heating drawings required by the contract, are past due. Sepia drawings must be reviewed by the architect first and prints must be distributed on site afterwards
23/05/1988
Design Matters, Request for FeedbackSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Addressing the issues mentioned in a previous letter regarding the heating and ventilation drawing. Notifying Maxim Schrogin that this letter will serve as architectural approval that the new marked up drawings are approved regarding aesthetic design
25/05/1988
Planning of Works, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Informing Christopher Alexander on the amount of time to be taken off, and forwarding the invoice with the hours of work spent this month
26/05/1988
Financial, Services FeeSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Confirmation for the request for gas and electric service to the Shelter for the Homeless. Noted are the responsibilities for the PG&E company and the Housing for Independent People, Inc., which includes backfilling, trenching, and substructures on the drawing. Inspection requirements are noted
02/06/1988
Planning of Works, NotificationSender:Linda M. Carlson, Pacific Gas and Electric Company, San Jose, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Requesting the previously agreed upon budget evaluation, regarding some problematical construction areas. Initiation of their construction awaits the C.E.S.'s evaluation of the budget's capacity to cover them, as promised
20/06/1988
Financial, BudgetSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Informing that the C.E.S. is ready to proceed with the second story exterior wall tile work for not delaying the construction plans, even without a signed contract, and expect to be paid in a timely fashion
27/06/1988
Construction Works, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Giving an evaluation on the construction of concrete beams and columns observed in the recent inspection, and informing on the issues discussed with Maxim Schrogin
27/06/1988
Construction Works, NotificationSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Letter of confirmation that Maxim Schrogin will not sign a subcontract before a review by Center for Environmental Structure
27/06/1988
Contractual, Construction ContractSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Informing on the changes that will take place regarding the way of handling, signing, and submitting, the change orders from now on
29/06/1988
Progress of Works, MemorandumSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Confirming issues discussed on the phone regarding the kitchen layout, the specific equipment design profiles, and the requested revisions to be made
02/07/1988
Design Matters, MemorandumSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Steve Shipe, Keystone Company, San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Specifying the exact terms of work for Henry Sterngold, which should be only under the direction of Christopher Alexander and Gary Black. If he birches this term, he will have to withdraw from the project
08/07/1988
Administrative, NotificationSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding the approval letter from the Santa Clara County Health Department for the food serving area of the kitchen and stating the two corrections required to be made before their inspection. A request is made to the contractor to comply and arrange for the inspections
08/07/1988
Construction Works, NotificationSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding the Pacific Gas & Electric and the San Jose Water Company requirements
13/07/1988
Design Matters, NotificationSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding a summary of the 12 changes that are scheduled to be made at this point, regarding the project. Each change is listed with the corresponding costs, some approximated
18/07/1988
Financial, Cost EstimateSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Gary Black, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding a requested revision drawing of the courtyard soil treatment
27/07/1988
Design Matters, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Request for bids to be obtained regarding the dining hall windows. A drawing with a window elevation depicting an approximate muntin arrangement, is attached
25/07/1988
Financial, Cost EstimateSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Informing on the revised masonry wall heights along the arcade. Request to inform the mason and obtain credit for the reduced amount of masonry needed
25/07/1988
Design Matters, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Bid for the installation of two street light poles
25/07/1988
Financial, Cost EstimateSender:John F. Casey, Allied Electric Company, San Jose, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Requesting the submittal of a cost breakdown to be provided by the contractor and all subcontractors when a Change Order is submitted in order to be processed
26/07/1988
Financial, Cost EstimateSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Fire sprinklers and fire alarm. Addressing the issue of corrections made on the sprinkler system layout, and informing they were reviewed by the Fire Dept. Also advising the contractor on how to precede with the installation
29/07/1988
Construction Works, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Informing about design changes being implemented for the walls at the day room entry, arcade, and parallel to the arcade. Overview provided with a formal directive to follow
29/07/1988
Construction Works, NotificationSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding a revised drawing by the Pacific Gas and Electric Company, and instructing on the immediate steps to be taken to facilitate these electric installations and inspection
29/07/1988
Construction Works, NotificationSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding the two drawings provided by the San Jose Water Company and instructing on the immediate steps to be taken to facilitate the installations and inspection
30/07/1988
Construction Works, NotificationSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Requesting for a new set of As-Built sepia drawings to be kept at the jobsite for electrician, plumber, and mechanical contractor to update daily with work completed
02/08/1988
Construction Works, NotificationSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Requesting the immediate resolution of a conflict between the architect and the subcontractor who is to install the main lobby deck, regarding its installation and costs having been provided already or not
02/08/1988
Contractual, Construction ContractSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Request for an update on thirteen outstanding issues. There are items such as window schedule and orders, door and hardware, stairway, footings, and framing over new masonry. Additionally, inspector requests, truss approval, indemnification, roofing. Requesting an immediate review and approval of specific bid and change orders
03/08/1988
Construction Works, Outstanding IssuesSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Gary Black, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Requesting the immediate provision of sets of all catalogue cuts regarding the kitchen equipment; to be forwarded to all entities involved with the construction
03/08/1988
Construction Works, Request for FeedbackSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:John Bidwell, Keystone Company, San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Results from the inspection of the finished carpentry at the lobby ceiling. Findings are included that discuss improper workmanship with their description. Recommendations for repair to the findings are spelled out in detail
09/09/1988
Construction Works, Response to RequestSender:Larry Meyer, City of San Jose, San Jose, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Responding to complaints about the problematic behavior of the construction manager towards the C.E.S. people. Apologizing again and explaining that the unavailability of the architect or whomever is assigned to solve occurring design gaps and unclarities on a timely manner hurts the project. One such person is absolutely needed on a continuous base
19/09/1988
Administrative, Request for FeedbackSender:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Responding to an invoice sent by the Center for Environmental Structure by explaining the points of disagreement regarding the work claimed; response also sent via mailgram is included
20/09/1988
Financial, Response to RequestSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Discussing all unresolved yet design issues which considerably surpass the allowed budget and requesting redesigning and/or new bids to be made following the budget limits, all issues that are seriously delaying the construction. The overdue current payment to the contractor is also mentioned
28/09/1988
Construction Works, Request for FeedbackSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Gary Black, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Responding to the A.J. Miller & Associates request for an additional payment, exceeding that of the engineering contract and of the already approved and paid additional work. Requesting invoices of proof for the extra claims
05/10/1988
Financial, Response to RequestSender:Kristie Hatten, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:A.J. Miller, Structural Engineering Corportation, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding a list of all changes to be made, subsequent to the most recent change orders submitted. Two kinds of changes are listed, ones that have their cost included, and those of the "no-charge" category
10/11/1988
Construction Works, NotificationSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Jullian Street Inn - Shelter for the Homeless: A subcontract has been issued to Carl Lindberg within the budget allowance of Oliver & Company Inc.. Wishing that this can assure the completion of the arcade in accordance with everyone's aesthetic and financial satisfaction
11/10/1988
Contractual, NotificationSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Reminding of the fact that a proof of insurance has not yet been provided by the C.E.S., which is required for the construction subcontract to be authorized
11/10/1988
Legal Issue, Outstanding IssuesSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: A follow up written report of all verbal discussions and decisions made during various field meetings. A synopsis of one of seven meetings is described as an appraisal for Henry Sterngold
11/10/1988
Progress of Works, NotificationSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Commendation for adding James McGuire to the project, though the lack of timely decisions and answers is a remaining concern. A full-time access of one person providing answers, is crucial for a smooth operation
12/10/1988
Progress of Works, NotificationSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Expressing the architect's categorical rejection of the different instructions given by the owner regarding door orders, and the wood fascia; instructions were contrary to those given by architect. Article 2.2.11 is thereby invoked. Written approval is required before any change
20/10/1988
Construction Works, Response to RequestSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Mailgram
-
The Julian Street Inn - Shelter for the Homeless: Setting the limits of what people can enter the construction site and making sure that unauthorized personnel cannot alter the work in place. It is a matter of insurance and security, as well as assurance of avoiding further damages
24/10/1988
Contractual, NotificationSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Clarifying to the City of San Jose Building Department that all changes to the project from the permit drawings are the responsibility of the owner (HIP) only, who will then demand updates and corrections to be made by the architect. Requesting for approval of framing and subsequent inspections
31/10/1988
Design Matters, Request for FeedbackSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Informing the owner and the architect on the results of the field inspector's evaluations. Issue of the second story wood windows must be resolved immediately. Reminding also of the city's request for the updated permit drawings to be provided
02/11/1988
Construction Works, Outstanding IssuesSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Proposal for revised storm drain at Housing for Independent People, Inc. Providing information on cost and specifications for this job
09/11/1988
Financial, Cost EstimateSender:Clyde Lawler, Lawler & Stanz Inc., Fairfield, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Requesting a proposed method of creating an egress through a second floor window, as soon as possible
03/11/1988
Construction Works, NotificationSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Telegram
-
The Julian Street Inn - Shelter for the Homeless: Addressing the issues communicated to the contractor by the architect and the owner in two different mailgrams dated 20-Oct-1988 and 3-Nov-1988: the fascia and the window egress. Updating on the status of each issue
03/11/1988
Construction Works, NotificationSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Urging Al DeLudovico to address four, previously requested, important but still pending issues, hoping for a fast and smooth resolution and continuation of the project. The four issues are restated in detail
15/11/1988
Financial, Outstanding IssuesSender:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: RE: Housing for Independent People Mechanic's Lien Forms. Forwarding two forms of mechanic's liens, one for architectural and the other for subcontractor services, and giving instructions on how they must be filled out and signed
16/11/1988
Legal Issue, Outstanding IssuesSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Casalnuovo, Vannelli & Nadel, San Francisco, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Notification with the requirements of the building inspector regarding the drawing updates needed in relation to the changes proposed by the change orders
17/11/1988
Design MattersSender:Al DiLudovico, Housing for Independent People Inc., San Jose, Ca, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Responding to contractor's topics of concern and explaining in detail the current status of all four points previously stated. Al DiLudovico is also expressing his discontent with the contractor's performance on specific issues
01/11/1988
Financial, Outstanding IssuesSender:Al DiLudovico, Housing for Independent People Inc., San Jose, Ca, U.S.A.Recipient:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Informing on the architect's changes regarding the lattice work shown on the initial drawings of the Kitchen, Laundry and Shower building South elevation
17/12/1988
Financial, Outstanding IssuesSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Contract with Center for Environmental Structure. Forwarding a copy of the mechanic's lien and of the preliminary 20-day notice for the work that the Center for Environmental Structure will be doing on the tilework
05/12/1988
Legal Case, TransmittalSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Casalnuovo, Vannelli & Nadel, San Francisco, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Contract with Center for Environmental Structure. Forwarding a copy of the mechanic's lien and of the preliminary 20-day notice for the work that the Center for Environmental Structure will be doing on the tilework
05/12/1988
Legal Case, TransmittalSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Casalnuovo, Vannelli & Nadel, San Francisco, CA, U.S.A.Recipient:Manny, Housing Department of San Jose, San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Contract with Center for Environmental Structure. Forwarding a copy of the mechanic's lien and of the preliminary 20-day notice for the work that the Center for Environmental Structure will be doing on the tilework
05/12/1988
Legal Case, TransmittalSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Casalnuovo, Vannelli & Nadel, San Francisco, CA, U.S.A.Recipient:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding three change orders requesting signature.
29/03/1988
Administrative, TransmittalSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding sixteen proposed change orders, referred to as necessary and/or as discretionary. Description of estimated costs and contract changes is provided.
09/09/1988
Administrative, TransmittalSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Handwritten letter reporting on the current schedule of activities, events and issues needing to be addressed and answered. Mentioned attachments are missing.
23/10/1988
Construction Works, InformativeSender:James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: A note written on a page with a sketch of the window grills at the courtyard entry, including sizes of rods, anchors and rough construction information.
01/01/1988
Design Matters, Request for FeedbackSender:James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Note
-
The Julian Street Inn - Shelter for the Homeless: Commenting on each proposed Change Order included in the analysis sent by Oliver and Company on 10-Nov-88.
21/11/1988
Administrative, Request for FeedbackSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Responding to general contractor's claims and incorrect assessments about the levels of construction completion and of overcharging for them.
21/11/1988
Administrative, Response to RequestSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Informing about the lack of exact, clear measurements provided by the plumbing plans that could result in wrong or inaccurate pipping placement in the slabs.
23/03/2024
Construction Works, InformativeSender:Mitchel J. Portera, Metro Plumbing, San Jose, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Responding to concerns over door widths and the fire ratings of certain doors as discussed during a meeting. A list of the requirements by which the specified doors must comply.
18/08/1988
Administrative, Design StandardsSender:Jeff Weber, Bureau of Fire Prevention, San Jose Fire Department, San Jose, CA, U.S.A.Recipient:Roland Angenent, Berkeley City Club, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Message note by the general contractor to HIP, reminding that the discount offer will only be valid if progress bill #7 is paid by 10-9-88.
31/08/1988
Financial, Service FeeSender:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Note
-
The Julian Street Inn - Shelter for the Homeless: Personal note to Christopher Alexander together with forwarding a letter already sent to Gary Black; expressing interest about the possibility in collaborating with him in the Julain Street Inn project.
12/05/1988
Prospect of Project, Request for FeedbackSender:Ray G. Perman, Kenner-USA Inc., Oakland, CA, U.S.A.Recipient:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding for approval a reference document with information about electrical panel cuts
03/08/1988
Design Matters, Request for FeedbackSender:Maxim Schorgin, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Artemis Anninou, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Bond - Forwarding an initial summary of the 1987 books and accounting records of the Center for Environmental Structure, Inc.; further analysis required for completing the accounting for 1987.
29/02/1988
Financial, TransmittalSender:Steven Kliegman, Certified Public Accountant, Oakland, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Bond - Requesting additional financial information to be provided, as required by the surety for approving a bond to the Center for Environmental Structure.
08/04/1988
Financial, Request for FeedbackSender:Gordon W. Richards, R. C. Fischer & Co., Oakland, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Bond - Forwarding the completed Contractors Surety Application Questionnaire and copies of C.E.S.'s financial Statements for evaluation, together with a check covering the appraisal fee; one draft hand-filled Application Questionnaire is also included
11/05/1988
Financial, Informative, TransmittalSender:Marian Wattman Oshima, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Gordon W. Richards, R. C. Fischer & Co., Oakland, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Bond - Confirming the delivery of documents to the Amwest Surety Insurance Company appraisers sent by the Center for Environmental Structure
18/05/1988
Administrative, InformativeSender:Gordon W. Richards, R. C. Fischer & Co., Oakland, CA, U.S.A.Recipient:Marian Wattman Oshima, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Bond - Informing the Amwest Surety Insurance Company about the status of the account of the Center for Environmental Structure with the bank
07/06/1988
Financial, InformativeSender:Nancy Lawrence, Wells Fargo Bank, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Bond - Answering to previously requested clarifications regarding the property the Center for Environmental Structure is using for collateral for its construction bond
18/10/1988
Financial, InformativeSender:Marian Wattman Oshima, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Gordon W. Richards, R. C. Fischer & Co., Oakland, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Design proposal and cost estimate for the installation of water facilities to serve the buildings according to the attached final plans.
02/02/1988
Design Matters, Subcontracting ServicesSender:Wayne S. Waren, San Jose Water Company, San Jose, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Two official notifications issued by the San Jose Fire Department informing on the new sign off inspection form to be used at the job site and on the increase of the inspection fees
31/08/1988
Administrative, NotificationSender:John F. Feld, City of San Jose, San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Bid offer for furnishung labor and materials for a concrete block capping above the finished floor in the dining hall
27/07/1988
Contractual, Subcontracting ServicesSender:Elwood L. Smith, E & S Masonry Inc., Castro Valley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Letter responding to a request for presenting various examples showing the special attention given by the Center for Environmental Structure to the design-decision process and the execution of special building features
29/01/1989
Design Matters, Response to RequestSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Response to a request for a modification two main entry doors of the dining hall; sketch attached
08/03/1989
Design Matters, Response to RequestSender:James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Request to relinquish Center for Environmental Structure as subcontractor from performing certain items of work listed as part of the contract
02/02/1989
Contractual, Construction ContractSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Letter with attachment outlining the serious deficiencies and delays allegedly caused by Center for Environmental Structure
14/03/1989
Contractual, Outstanding IssuesSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: General Contractor's Claim for Delay Time. A letter indicating that a deep analysis has been completed regarding a $43,245.00 claim presented by Maxim Schrogin in a 3-Mar-1989 letter. After careful study, a conclusion was made that it has not merit and Housing for Independent People, Inc., does not need to pay the claim. An Architects report will follow. Unsigned
18/04/1989
Contractual, NotificationSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Requesting from the Center for Environmental Structure to resume immediatelly its work according to the contract and resolve the issue of Carl Lindberg's payment for his labor work later
19/01/1989
Contractual, Outstanding IssuesSender:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Gary Black, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: New filing procedure with County Recorder in Housing for Independent People Project. Forwarding two copies of preliminary lien notices requiring an original signature as soon as possible, for filling them on time
17/01/1989
Legal Issue, Outstanding IssuesSender:Edward W. Scott, Attorneys at Law - Dobbs, Berger, Molinari, Casalnuovo, Vannelli & Nadel, San Francisco, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Plea for payment of past due bills and lien ultimatum
01/06/1989
Financial, Request for PaymentSender:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Steven H. Oliver, Al DiLudovico, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Letter indicating numerous misleading and crucial misstatements in a previous letter with a list of comments related to them
03/06/1989
Contractual, Outstanding IssuesSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Correcting all the missinformation expressed in a previously sent request by Steve Oliver regarding the payment for labor to Carl Lindberg. In addition, points requiring correction and immediate resolution by the Oliver Construction Co., are listed
22/01/1989
Contractual, Outstanding IssuesSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Request for settling past due payment of $150,000 in full or in part, otherwise work demanded cannot not be assigned. Other compromises are discussed
29/09/1989
Financial, Request for PaymentSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Notification that the claims made in a previous letter are in error and a violation of agreement. Outline of reasoning is included
26/10/1989
Contractual, Response to RequestSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: New Filings. Advice on the filling and recording of the lien and information on the immediate steps to be taken in a timely manner in order to meet the foreclosure deadline. Required actions are also described in case a Notice of Completion or Cessation is filed before the deadline
10/02/1989
Legal Issue, Outstanding IssuesSender:Edward W. Scott, Attorneys at Law - Dobbs, Berger, Molinari, Casalnuovo, Vannelli & Nadel, San Francisco, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Expressing concerns regarding the "heat bend" procedure for the #10 rebars for the gunnite truss and recommending additional reviews, and requesting attestations by the structural engineer/designer regarding the finally produced bending angles
15/03/1989
Construction Works, Construction ProcessSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Correcting the section, page and table numbers referenced in a previous correspondence regarding the Unified Building Code requirements
20/03/1989
Construction Works, Construction ProcessSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Reminding on the requirement to have the owner's approval before instigating additional work or change orders that cause additional construction costs. Lack of approval frees the owner from any responsibility to cover these costs
10/05/1989
Financial, NotificationSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re-transmitting a document sent by the City of San Jose Rehabilitation Inspector after detecting ceiling defects, and asking for repair recommendations
12/05/1989
Construction Works, Request for FeedbackSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Urging the Center for Environmental Structure to provide the completed remodeling drawings for the existing building, in compliance with the Uniform Building Code requirements. Serious economic repercussion will follow if final date for filing is not respected
12/05/1989
Design Matters, InformativeSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Reminding on the immediate need to have the recommendations for repairing and finishing the wood beams in the lobby and dayroom
19/06/1989
Construction Works, Request for FeedbackSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Expressing some serious concerns about 1. Giving different, verbal orders on-site regarding the stucco application technique; 2. Problematic thin glazing on the tiles prone to scratching; 3. Unauthorized people from the C.E.S. purporting on the site causing work complications and safety issues
23/06/1989
Construction Works, Construction ProcessSender:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Expressing concerns about a clarification recently sent by the C.E.S. and requesting an answer on its applicability for remedying the Lobby ceiling beams
06/07/1989
Construction Works, Request for FeedbackSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Notifying about the need to correct the detail of the enclosure for the fire sprinkler riser at the entrance of the shelter to conform to the Fire Marshal's requirements
06/07/1989
Construction Works, Request for FeedbackSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Gary Black, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Informing that the concrete bench backs constructed by the C.E.S. without obtaining the owner's approval, will not be financed by the owner if cost exceeds $400.00
06/07/1989
Construction Works, NotificationSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Gary Black, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Notice that the letter received is completely rejected as it is perceived to be without factual basis or correctly drawn conclusion
11/07/1989
Administrative, NotificationSender:Steven H. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Note
-
The Julian Street Inn - Shelter for the Homeless: A written reminder that all work on the shelter much be completed by 30-Jul-1989 so, color codes must be provided, and complete cooperation is expected
14/07/1989
Construction Works, NotificationSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Gary Black, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: In response to the letter addressing the concrete bench backs being constructed without authorization, reminds that this issue was discussed and authorized weeks before construction started
15/07/1989
Construction Works, NotificationSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Requesting a prompt resolution to all issues relating to the Fire Marshall's requirements and correction of the submitted drawings to meet the zoning requirements; all issues delaying the permit issuance
19/07/1989
Legal Issue, NotificationSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:James Maguire, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Demanding an immediate solution for the fire sprinkler riser at the entrance of the shelter, as the one submitted was rejected, and assuming any additional costs this work might require
02/08/1989
Legal Issue, NotificationSender:Gary Black, James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Requesting update on the Building Permit status and an exact date to be expected
02/08/1989
Legal Issue, NotificationSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:James Maguire, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Request for a construction review and recording of all observations made in a "punch list" to be submitted to the architect and the owner as soon as possible
07/08/1989
Construction Works, Request for FeedbackSender:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Maxim Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Demanding for the removed paint off the bench backs to be repaired at once
11/09/1989
Construction Works, NotificationSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:James Maguire, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Expressing strong concerns for the delay of obtaining the Building Permit for rehabilitating the existing storage shed
22/09/1989
Construction Works, Request for FeedbackSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:James Maguire, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Informing Christopher Alexander that, since the contractor has not done so, it is now up to the C.E.S. to prepare the "punch list" with observations; on-site inspection date needs to be established
26/09/1989
Construction Works, Request for FeedbackSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Center for Environmental Structure v. Homes for Independent People, et al., Santa Clara Superior Court Nos: 682110 and 690-895. Notifying about the two mechanics liens filed and recorded against the property, and forwarding copies of the respective summons and complaint for each of the enclosure actions. Request to sign and return in the included envelope to serve as Notice of Acknowledgement of Receipt
06/10/1989
Legal Case, NotificationSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Casalnuovo, Vannelli & Nadel, San Francisco, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Notice of Default: Demanding the C.E.S. to comply with its construction obligations, namely, to conduct inspections and prepare a "punch list" determining substantial and final completion of the project. Failing to perform these previously requested inspections have caused delays, and the need for hiring another architect or qualifying person to do so will be enforced
13/11/1989
Legal Case, Request for FeedbackSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding an invoice with detailed breakdown of the C.E.S. construction work, and explaining the reasoning for the past due amounts and request for payment
30/11/1989
Financial, Request for PaymentSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Letter answering to the request of additional services regarding the renovation of an existing on-site structure
01/01/1989
Administrative, Response to RequestSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Letter responding to a reminder by Al DiLudovico, informing that requested information was forwarded to contractors and himself on 18-Nov-88
26/06/1989
Administrative, Response to RequestSender:James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Draft of a letter providing an overall review of the existing situation, regarding the shift of purpose and function of the shelter, away from the initially imagined. It highlights the elements which need care and attention in order to accomplish its purpose in providing a dignified way of living.
26/05/1989
Status of Project, NotificationSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding a copy of the complaint to foreclose the HIP mechanic's lien recently filed and requesting a call back for planning the following actions
09/05/1989
Legal Case, Request for FeedbackSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Casalnuovo, Vannelli & Nadel, San Francisco, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Responding to Alrie Middlebrook, the Landscape Architect of the project, to inform her of the C.E.S. final bill to HIP and the amount owed.
01/02/1990
Financial, NotificationSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA , U.S.A.Recipient:Arlie Middlebrook, Middlebrook, Kamph and Ing - Landscape Architects, San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: RE: 20 Day Preliminary Notice. Three copies of Notices of Completion dated 8-Mar-1990 issued by the City of San Jose in response to three notices filed by C.E.S. in February 1989 and 1990.
10/04/1990
Legal Issue, NotificationSender:Bob Horiuchi, County of Santa Clara, San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Response to request by the client for punch list and the difficulties of doing so, after having received no funds; reference to the issuance of the certificate of substantial completion
11/01/1990
Financial, Response to RequestSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Letter titled "Punch List Notice of Items Required for Final Completion" with 11-page attachment listing in detail the items of the building which need to be corrected for the final completion of works
14/01/1990
Construction Works, Response to RequestSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Demanding issuance of a lien for the final amount owed to Center for Environmental Structure. Attached are eight pages of the "Final Bill for Architectural Services, Project Management and Construction Work" in accordance with the architectural contract
01/02/1990
Legal Issue, Outstanding IssuesSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Vannelli, Nadel & Links, San Francisco, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Mechanic's Lien for Housing for Independent People Project. Copy of new Lien and instructions for filing included
01/02/1990
Legal Case, TransmittalSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Casalnuovo, Vannelli & Nadel, San Francisco, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Housing for Independent People Settlement - Eighteen pages containing the latest three documents. Documents forwarded: 1) a partial letter by the Housing for Independent People's attorney with the updates included in the revised agreement, 2) a revised summary of claims by the contractor and 3) the revised 'Project Close-Out Agreement'. The transmittal note is asking for review and discussion ASAP
05/07/1990
Legal Case, Request for FeedbackSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Vannelli, Nadel & Links , San Francisco, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Demanding a fair approach by the City of San Jose Housing Department in settling the claims of payment by both, Oliver &Company and by the Center for Environmental Structure simultaneously, or not at all
06/04/1990
Financial, Request for PaymentSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Alex Sanchez, Housing Department of San Jose, San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Response stating the Housing Department's responsibility extending only to the approved contracted amount between the Housing for Independent People and the general contractor
10/04/1990
Financial, Response to RequestSender:Alex Sanchez, Housing Department of San Jose, San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Three letters relating to problems that occurred during the construction of the stucco wall and the placement of the second-floor tiles because of the wrong handling of them; sent for legal purposes
25/05/1990
Legal Issue, Outstanding IssuesSender:James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Fax
-
The Julian Street Inn - Shelter for the Homeless: Letter with draft settlement agreement attached
18/06/1990
Legal Case, TransmittalSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Vannelli, Nadel & Links , San Francisco, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Fax
-
The Julian Street Inn - Shelter for the Homeless: Response to the settlement agreement indicating that it is not as previously negotiated. Detailed analysis of situation is included
06/07/1990
Legal Case, Request for FeedbackSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Vannelli, Nadel & Links , San Francisco, CA, U.S.A.Recipient:Thomas H. Squeri, Attorneys at Law - Pettit & Martin, Santa Clara, CA, U.S.A.Medium:Fax
-
The Julian Street Inn - Shelter for the Homeless: Letter with enclosures including the Housing for Independent People settlement agreement and instructions for finalizing. Also are court copies of submitted documents and agreements thereto
23/07/1990
Legal Case, TransmittalSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Vannelli, Nadel & Links , San Francisco, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Housing for Independent People, Inc. Settlement modification to the Project Close-Out Agreement with instructions on how to complete
07/08/1990
Legal Case, TransmittalSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Vannelli, Nadel & Links , San Francisco, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding the 12-page "Punch List Notice of Items Required for Final Completion" prepared by C.E.S., with review and edit notes for each pending item, regarding their completion level
25/07/1990
Legal Case, Response to RequestSender:Thomas H. Squeri, Attorneys at Law - Pettit & Martin, San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Fax
-
The Julian Street Inn - Shelter for the Homeless: Re: Housing for Independent People Settlement - Forwarding a copy of the executed settlement agreement signed by all by 31-Jul-1990. Also, expressing personal wishes and comments for the new teaching semester and the upcoming carpet exhibit; 14 pages
07/08/1990
Legal Case, TransmittalSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Vannelli, Nadel & Links , San Francisco, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Escrow instructions of Housing for Independent People, Inc. Escrow No. 294739-DNH. The document constitutes Housing for Independent People, Inc. instructions to the Escrow Holder. A list of seventeen instructions and what amounts will be paid to each participant in the lawsuit as well as instructions to close
18/07/1990
Legal Case, Request for FeedbackSender:Thomas H. Squeri, Attorneys at Law - Pettit & Martin, San Jose, CA, U.S.A.Recipient:Diva Holliday, California Land Title Company, San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Housing for Independent People, Inc./Oliver & Co./Center for Environmental Structure. A letter listing multiple documents that must be addressed and once completed and signed, returned and delivered to escrow so that the settlement can be consummated
20/07/1990
Legal Case, Request for FeedbackSender:Thomas H. Squeri, Attorneys at Law - Pettit & Martin, San Jose, CA, U.S.A.Recipient:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Vannelli, Nadel & Links, San Francisco, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Re: Housing for Independent People, Inc. (H.I.P.) / Oliver & Co. / Center for Environmental Structure (C.E.S.) Escrow No 294739-DNH. Authorization to file Request for Dismissal and record the release of Mechanics' Lien after a check for $78,500.00 made payable to C.E.S. has been delivered. Additional request for final documents
23/07/1990
Legal Case, Request for PaymentSender:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Vannelli, Nadel & Links , San Francisco, CA, U.S.A.Recipient:Diva Holliday, California Land Title Company, San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Draft of a letter forwarding information and a "punch list" of the so-far not completed items, as well as all remedies and corrections which are required for the building to achieve its proper completion according to plan; not sent
04/01/1990
Construction Works, InformativeSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter Draft
-
The Julian Street Inn - Shelter for the Homeless: Notification that since a punch list has not been created after multiple request attempts and several months to urge its completion, if it is not completed by 10-Jan-1990, a Notice of Default will be invoked
08/01/1990
Construction Works, NotificationSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless:Â Explaining why the Housing for Independent people is not responsible for paying the invoices sent to them by the Center for Environmental Structure, as it has never made any verbal commitment that the C.E.S. can provide and install material on the project
11/01/1990
Financial, Outstanding IssuesSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless:Â Explaining why the "punch list" has been so delayed, promising it will be handed in by next week and asking for an official request for the issuance of the certificate of completion
01/01/1990
Construction Works, Outstanding IssuesSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Confirming the final bill was received and requesting some more information on the project and Christopher Alexander's own perspective for the landscape
06/02/1990
Design Matters, Request for FeedbackSender:Alrie Middlebrook, Interior Landscape Design, Stockton, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Denying the charges imposed by the final bill as lacking foundation and informing that the issue will be addressed by the attorneys of both sides
22/02/1990
Financial, Response to RequestSender:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: An inquisition about how the policies is enacted for paying contractor bills in advance of other settlements, specifically the settlement owed to Center for Environmental Structure, due to political pressures. A request for a response is urged
06/04/1990
Financial, Request for PaymentSender:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Recipient:Alex Sanchez, San Jose Housing Department, San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Transmitting the letters between attorneys John Marshall Collins, Tom Squeri and Robert D. Links. All these letters regard the dispute between the Center for Environmental Structure, the owner, and the contractor
11/04/1990
Legal Case, TransmittalSender:Thomas H. Squeri, Attorneys at Law - Pettit & Martin, San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Fax
-
The Julian Street Inn - Shelter for the Homeless: Explaining the city's role as that of a construction lender to the Housing for Independent people, which has no responsibility to determine the merits of any claim in relationship to HIP or the general contractor
24/04/1990
Legal Issue, NotificationSender:Tom McEnery, City of San Jose, San Jose, CA, U.S.A.Recipient:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Letter explaining the importance of consulting with Christopher Alexander "whenever physical changes are contemplated in the building fabric", affecting the original design of the building. Color, planning and design accuracy as advised, especially for the dining room and the trusses are crucial.
02/02/1991
Progress of Works, NotificationSender:Christopher Alexander, Center for Environmental Structure , Berkeley, CA, U.S.A.Recipient:Peter Myron Conk, San Jose, CA, U.S.A.Medium:Letter
-
The Julian Street Inn - Shelter for the Homeless: Forwarding a previously sent letter describing Christopher Alexander's desire to continue as consultant whenever major decisions affecting the original design of the building would be made.
22/03/1991
Progress of Works, NotificationSender:Marian Wattman Oshima, Center for Environmental Structure , Berkeley, CA, U.S.A.Recipient:Bill Shean, Urban Ministries, San Jose, CA, U.S.A.Medium:Fax
-
The Julian Street Inn - Shelter for the Homeless: Forwarding a previously sent letter describing Christopher Alexander's desire to continue as consultant whenever major decisions affecting the original design of the building would be made.
25/03/1991
Legal Issue, TransmittalSender:Marian Wattman Oshima, Center for Environmental Structure , Berkeley, CA, U.S.A.Recipient:Robert D. Links, Attorneys at Law - Dobbs, Berger, Molinari, Vannelli, Nadel & Links, San Francisco, CA, U.S.A.Medium:Fax
-
The Julian Street Inn - Shelter for the Homeless: Forwarding the specifications for the interior of the dining hall as requested and informing about a video tape sent. Also, asking for immediate review and setting an appointment.
03/04/1991
Construction Works, Response to RequestSender:Marian Wattman Oshima, Center for Environmental Structure , Berkeley, CA, U.S.A.Recipient:Bill Shean, Urban Ministries, San Jose, CA, U.S.A.Medium:Fax
SEE ALL Correspondence
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set B of drawings for the "Building Complex" - Elevations
10/07/1987
Architectural Design, Permit Drawing, ElevationDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/8"=1'Architectural drawing with elevations of the North, West, East and South facades of the complex.
-
The Julian Street Inn - Shelter for the Homeless: Sketches
01/01/1986
Architectural Design, Sketches, Floor PlanDesigners:Christopher Alexander, Berkeley, CA, U.S.A.Medium:Original on PaperSize:10 5/8"x13 5/8"Scale:1:20Three pages with sketches; the first includes the ground floor plan of the building layout and the interior gardens formed, with a small axonometric, while the other two include the outline of the lot and its dimensions .
-
The Julian Street Inn - Shelter for the Homeless: Sketches
01/01/1986
Architectural Design, Sketches, Floor PlanDesigners:Christopher Alexander, Berkeley, CA, U.S.A.Medium:Original on PaperSize:8 1/2"x11"Scale:1:20Sketch of an early version of the ground floor plan of the building layout and the interior gardens formed, including a small axonometric of it .
-
The Julian Street Inn - Shelter for the Homeless: Sketches
01/01/1986
Architectural Design, Sketches, Floor PlanDesigners:Christopher Alexander, Berkeley, CA, U.S.A.Medium:Original on PaperSize:11"x14"Scale:1/2"=1'Sketch of an early version of the ground floor and second floor plans of the building layout and the interior gardens formed .
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set B of drawings for the "Building Complex" - Cover Pages
10/07/1987
Architectural Design, Permit Drawing, Drawing Index, Specifications, NotesDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Two sheets, the first titled Drawing Index, and the other, General Notes, Structural Specifications, Abbreviations and Symbols.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set B of drawings for the "Building Complex" - Site Plan
25/08/1987
Architectural Design, Permit Drawing, Site PlanDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/20"=1'Revised architectural drawing depicting the building complex as it was laid out on the site, and including a vicinity map and a building-code summary table.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set B of drawings for the "Building Complex" - Grading and Foundation Plans
10/07/1987
Structural Design, Permit Drawing, Foundation PlanDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/8"=1', 1/2"=1', 1"=1'Four structural drawings, including 1) Grading plan with sections; 2) Foundation plan and details; 3) Plan of concrete slabs; 4) Foundation details.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set B of drawings for the "Building Complex" - Floor Plans
08/09/1987
Architectural Design, Permit Drawing, Floor Plan, DetailsDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/8"=1'Three architectural floor plan drawings: 1) Ground Floor plan; 2) Second Floor plan; 3) Roof Plan.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set B of drawings for the "Building Complex" - Electrical Plans
10/07/1987
Electrical Design, Permit Drawing, Floor PlanDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/8"=1'Two floor plans with the layout of all electric lines and connections.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set B of drawings for the "Building Complex" - Fire Protection Plans
10/07/1987
Mechanical Design, Permit Drawing, Fire Protection PlanDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/16"=1'Drawing illustrating all necessary fire-resistant walls and all protected areas .
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set R of drawings for the "Residential Building" - Drawing Index
27/08/1987
Architectural Design, Permit Drawing, Drawing IndexDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Sheet listing the set of drawings for the Residential Building .
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set R of drawings for the "Residential Building" - Framing Plans
27/08/1987
Structural Design, Permit Drawing, Floor PlanDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/8"=1', 1"=1'Three framing plans with additional explanatory details related to specific wood connections and construction specifications.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set R of drawings for the "Residential Building" - Cross and Longitudinal Sections
27/08/1987
Architectural Design, Permit Drawing, SectionDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/8"=1'Drawing with two longitudinal and two cross sections as they were revised on 27-Aug-1987.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set R of drawings for the "Residential Building" - Structural Drawings & Construction Details
27/08/1987
Structural Design, Permit Drawing, Section, DetailsDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/2"=1', 1"=1'Six structural drawings including: 1) & 2) Cross sections with specifications and detail references; 3) Vertical sections with architectural and structural details; 4) Concrete column details; 5) Concrete beam elevations; 6) Stud wall construction .
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set R of drawings for the "Residential Building" - Heavy Timber Details
27/08/1987
Structural Design, Permit Drawing, Axonometric, DetailsDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Two structural drawings with information on the heavy timber elements of the building structure. Included information refers to the reflected ceiling plan at the Main Lobby, and various detail sections of the ceiling’s wooden structure and other heavy timber details.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set R of drawings for the "Residential Building" - Windows, Doors & Finish Floor Plans
02/09/1987
Architectural Design, Permit Drawing, Floor PlanDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Two architectural floor plans with indications of the types of openings as mentioned in tables of door and window types with specifications; a schedule with interior finishes is included.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set R of drawings for the "Residential Building" - Front Porch & Exterior Staircase
10/07/1987
Structural Design, Permit Drawing, Floor Plan, Section, ElevationDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/2"=1'Two structural drawings including: 1) A section of the front porch and its structural specifications and 2) A section, an elevation and a plan of the exterior staircase and its specifications.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set R of drawings for the "Residential Building" - Miscellaneous Details
10/08/1987
Architectural Design, Permit Drawing, DetailsDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1"=1'Architectural drawing providing design and construction details of railings, staircase handrail, arcade lattice, iron gate, front and back porch-wall details.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set R of drawings for the "Residential Building" - Precast Panel Details
10/08/1987
Architectural Design, Permit Drawing, DetailsDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1"=1', 1/2"=1'Architectural drawing with construction details and specifications of various special details like railings, latices, low walls etc.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set R of drawings for the "Residential Building" - Precast Column Details
10/07/1987
Architectural Design, Permit Drawing, DetailsDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1"=1', 3"=1'Architectural drawing with the fabrication and assemby details of the precast columns and their capitals with ornaments.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set D of drawings for the "Dining Hall" - Drawing Index
10/07/1987
Architectural Design, Permit Drawing, Drawing IndexDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Sheet listing the set of drawings for the Dining Hall and its precast concrete truss.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set D of drawings for the "Dining Hall" - Plans and Structural Sections
10/07/1987
Structural Design, Permit Drawing, Floor Plan, Section, Elevation, Framing PlanDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/4"=1'Structural drawing of the Dining Hall, including a floor plan, a section and elevation of the arcade, a roof framing plan and window door and finishes schedules.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set D of drawings for the "Dining Hall" - Elevations and Sections
10/07/1987
Architectural Design, Permit Drawing, Section, ElevationDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/8"=1'Architectural drawing with elevations and sections of the Dining Hall, in the context of the building complex.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set D of drawings for the "Dining Hall" - Structural Sections and Details
10/07/1987
Structural Design, Permit Drawing, Axonometric, Section, DetailsDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1"=1', 1/2"=1'Structural drawing depicting sections of the Dining Hall and various details of the truss and the roof connections to walls.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set D of drawings for the "Dining Hall" - Concrete Truss
10/07/1987
Architectural Design, Permit Drawing, ElevationDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/2"=1'Two drawings of the concrete truss with notes on reinforcement placement and construction specifications.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set K of drawings for "Kitchen & Showers" - Drawing Index
10/07/1987
Architectural Design, Permit Drawing, Drawing IndexDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/2"=1'Drawing index for the Kitchen and Shower building.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set K of drawings for "Kitchen & Showers" - Floor Plans & Sections
10/07/1987
Architectural Design, Permit Drawing, Section, ElevationDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/8"=1'Two longitudinal sections through the Dining Hall and the kitchen with the laundry and showers annexed volume.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set K of drawings for "Kitchen & Showers" - Plans and Structural Cross Section
10/07/1987
Architectural Design, Permit Drawing, Floor Plan, SectionDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1/8"=1', 1/2"=1', 1"=1',Architectural drawing with plans, cross section, details and window & door schedules for the kitchen and shower areas; also a copy of the previous drawing with marked up items with detailed clarifications.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set L of drawings for "Landscape" - Planting Plan
10/09/1987
Landscape Design, Permit Drawing, Planting PlanDesigners:Mertin Kamph & Associates, Cupertino, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1"=20'Landscape design depicting the planting plan with materials and notes .
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set L of drawings for "Landscape" - Irrigation Plan
10/09/1987
Landscape Design, Permit Drawing, Irrigation PlanDesigners:Mertin Kamph & Associates, Cupertino, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1"=20'Landscape layout plan with a table of material types, notes and explanatory details .
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set L of drawings for "Landscape" - Irrigation Details and Specifications
10/09/1987
Landscape Design, Permit Drawing, Details, SpecificationsDesigners:Mertin Kamph & Associates, Cupertino, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:1"=20'Landscape drawing depicting the specifications for the irrigation installation and maintenance and additional installation details.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set L of drawings for "Landscape" - Planting Details and Specifications
10/09/1987
Landscape Design, Permit Drawing, Details, SpecificationsDesigners:Mertin Kamph & Associates, Cupertino, CA, U.S.A.Medium:BlueprintSize:24"x36 1/2"Scale:Landscape design drawing including planting details and specifications.
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Site Plan
11/05/1987
Architectural Design, Preliminary Design, Site PlanDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36"Scale:1/8"=1'Site plan depicting: the building complex as it should be laid out on the site, a vicinity map, and two tables, one with a schedule of landscaping, and the other the schedule of areas and capacities of the site.
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Floor Plans
11/05/1987
Architectural Design, Preliminary Design, Floor PlanDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36"Scale:1/8"=1'Three floor plans: 1. Ground floor plan with a window schedule and information on interior finishes; 2. Second floor plan and 3. Roof plan with roof drainage street and site drainage as well as roof material information.
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Elevations
11/05/1987
Architectural Design, Preliminary Design, ElevationDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36"Scale:1/8"=1'One drawing depicting the North, West and South elevations and includes a schedule of materials.
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Sections
11/05/1987
Architectural Design, Preliminary Design, SectionDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36"Scale:1/8"=1'Three drawings of various building cross sections through the residential building, the kitchen building and the dining hall for which there is an additional horizontal section of the roof framing.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set B of drawings for the "Building Complex"- Grading Plan
06/05/1987
Architectural Design, Permit Drawing, Grading PlanDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:Original on VellumSize:24"x36"Scale:1/8"=1'Grading plan of the building complex with the initial approval to begin site preparation and excavations for the foundation.
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Foundation & Framing Plans
06/05/1987
Architectural Design, Preliminary Design, Foundation Plan, Framing PlanDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36"Scale:1/8"=1'Four drawings depicting the foundations and the framing plans of the various levels of the building complex .
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Details
06/05/1987
Architectural Design, Preliminary Design, DetailsDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36"Scale:1/8"=1'Two drawings depicting: 1. Various concrete details of foundation, columns, beams, and connections to the stud walls 2. Main lobby ceiling design with details of its wooden members and connections.
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Schedule of Wall Openings
06/05/1987
Architectural Design, Preliminary Design, ElevationDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:Original on VellumSize:24"x36"Scale:1/8"=1'Two drawings containing all the exterior wall segments with the contained openings for doors and windows .
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Roof Curve Studies
06/05/1987
Architectural Design, Preliminary Design, DetailsDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:Blueprint, Original on tracing PaperSize:17"x22", 18"x30"Scale:1/8"=1'Three outline studies of the building curve, trying to set its center and angles; with dimensions.
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Floor Plan with Elevations
01/04/1987
Architectural Design, Preliminary Design, Floor Plan, ElevationDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36"Scale:1/8"=1'Three drawings depicting versions of floor plans and elevations, with several handwritten comments on them .
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Elevations
01/04/1987
Architectural Design, Preliminary Design, ElevationDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:Original on Vellum, BlueprintSize:24"x36"Scale:1/8"=1'Two studies of the west and the north elevations.
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Elevations
01/04/1987
Architectural Design, Preliminary Design, ElevationDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:Original on Vellum, BlueprintSize:24"x36"Scale:1/8"=1'Two studies of the south elevation.
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Elevation & Section through the Dining Hall
01/04/1987
Architectural Design, Preliminary Design, ElevationDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36"Scale:1/8"=1'One drawing depicting a section through the Dining Hall with an interior view of the Kitchen, laundry and bathroom building.
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Electrical Plan
06/05/1987
Electrical Design, Preliminary Design, Floor PlanDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36"Scale:1/8"=1'Two drawing sheets of the electrical layout for the ground floor and the second floor.
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Food Service Equipment
07/09/1987
Food & Beverage Equipment, Preliminary Design, Floor Plan, Elevation, Details, SpecificationsDesigners:Steve Shipe, San Jose, CA, U.S.A.Medium:BlueprintSize:24"x36"Scale:1/4"=1', 1/2"=1', 3/4"=1'Three drawings of a design proposal for the food service area of the kitchen, with mechanical, electrical and hydraulic studies which also include ventilation specifications and tables with general notes and symbols .
-
The Julian Street Inn - Shelter for the Homeless: Plan for the Improvement of Off-Site Improvements for the Shelter of the Homeless of the Southeast Corner of the Intersection of W. Julian Street and Montgomery Street
01/12/1987
Food & Beverage Equipment, Preliminary Design, Site Plan, Details, SpecificationsMedium:BlueprintSize:24"x36"Scale:1"=20'Drawing depicting a layout of the city’s public utilities, with specifications and guidelines of connecting to them; with detail sections and notes.
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Drainage Plans
15/04/1987
Mechanical Design, Preliminary Design, Drainage Plan, SpecificationsDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:PhotocopySize:11"x17"Two mechanical designs depicting drainage plans, notes and specification, studies with aproval seal and date of expiration.
-
The Julian Street Inn - Shelter for the Homeless: Building Permit set B of drawings for the "Building Complex" - Acoustic Shear Walls
10/07/1987
Architectural Design, Permit Drawing, Floor PlanDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36"Scale:1/8"=1'One drawing of the second floor plan depicting the acoustic shear-wall locations with red color.
-
The Julian Street Inn - Shelter for the Homeless: Preliminary Design Drawings- Parking Plan
01/04/1987
Architectural Design, Preliminary Design, Floor PlanDesigners:Christopher Alexander, Gary Black, Artemis Anninou, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:Original on Tracing PaperSize:18"x24"Scale:1/8"=1'One drawing of the onsite parking plan.
-
The Julian Street Inn - Shelter for the Homeless: Construction Drawings - Additional Information
30/06/1988
Architectural Design, Construction Drawings, DetailsDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:PhotocopySize:8 1/2"x11"Scale:1/8"=1'10-page set of clarification drawings with specific, additional information.
-
The Julian Street Inn - Shelter for the Homeless: Construction Drawings - Window Schedules & Details
04/11/1988
Architectural Design, Construction Drawings, DetailsDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:Original on Tracing PaperSize:8"x30", 19"x22", 24"x29Scale:1/8"=1', 1/2"=1', 1 1/2"=1, 1"=1'Six drawings with a revised window schedule of the building complex noted in plans, a side elevation of the kitchen and laundry building with window and door types, the design of a typical dining hall window, and window section details ...
-
The Julian Street Inn - Shelter for the Homeless: Construction Drawings MEP - Water Flow of Sprinkler System
04/03/1988
Mechanical Design, Construction Drawings, Floor Plan, Section, DetailsDesigners:Wayne S. Warren, Lafayette, CA, U.S.A.Medium:BlueprintSize:24"x36"Scale:1/8"=1'Two mechanical design drawing sheets for the sprinkler system installed in the building interior spaces and the exterior arcades; drawings include details of the pipe profiles and ceiling attachments, as well as building sections with the vertical layouts.
-
The Julian Street Inn - Shelter for the Homeless: Construction Drawings MEP - Gas and Electric meters
25/05/1988
Electrical Design, Construction Drawings, Floor Plan, ElevationDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:PhotocopySize:8 1/2"x11"Partial floor plan and elevation of the west end of the kitchen and showers building, depicting the new locations of the gas and electric meters, as they were finally approved by PG&E. Included are the added, handwritten notes by Linda ...
-
The Julian Street Inn - Shelter for the Homeless: Construction Drawings MEP - Heating System
24/08/1988
Mechanical Design, Construction Drawings, Floor Plan, Section, DetailsDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x36"Scale:1/8"=1', 3/8"=1'Two mechanical design drawing sheets for the heating system layout for the two building levels, and the attic section, with duct system details, and one detailed section through the combustion furnace room. Drawings include specification notes, corrections on the ventilation ...
-
The Julian Street Inn - Shelter for the Homeless: Construction Drawings - Roof Framing Plan
01/07/1988
Structural Design, Construction Drawings, Roof PlanMedium:BlueprintSize:24"x36"Scale:1/4"=1'Roof framing plan presented by a two-piece drawing with emphasis on the roof curvature in the first drawing, and with the special angles of the rest of the building’s roof in the second drawing; depicting the exact layout of rafters, ...
-
The Julian Street Inn - Shelter for the Homeless: As-Built Drawings - Building Layout & Grade Plan
01/03/1988
Architectural Design, As-Built Drawing, Site Plan, Grading Plan, Layout ProcessDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:Original on VellumSize:24"x36"Scale:1/8"=1'Two drawings which include the as-built grade levels of the site, as recorded on 1-Mar-1988, and the accurate layout of the building complex on the site.
-
The Julian Street Inn - Shelter for the Homeless: Construction Drawings - Change Order
16/02/1988
Architectural Design, Construction Drawings, DetailsDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:Original on Tracing PaperSize:8 1/2"x11"Scale:1 1/2"=1'Change order drawing regarding the construction of partition walls with a structural rating 50, as illustrated in two wall section details, one vertical and one horizontal, with notes and specifications.
-
The Julian Street Inn - Shelter for the Homeless: Construction Drawings - Change Order
11/03/1988
Architectural Design, Construction Drawings, DetailsDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:Original on Tracing PaperSize:8 1/2"x11"Scale:1/8"=1'Change order drawing regarding grade beams and columns, with details of the residential building’s curved part, depicting the beam and column layout and measurements.
-
The Julian Street Inn - Shelter for the Homeless: Structural Design Clarification - Dining Hall Roof
21/12/1988
Structural Design, Construction Drawings, Roof Plan, Section, DetailsMedium:Original on Tracing PaperSize:24"x36"Scale:1/2"=1', 1/8"=1'Structural drawing with the Dining Hall roof section, plan and details, in relation to the 2nd floor arcade structure, as well as two more section details with construction information.
-
The Julian Street Inn - Shelter for the Homeless: Construction Drawings - Elevation
01/01/1988
Architectural Design, Construction Drawings, ElevationDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:BlueprintSize:24"x93"Large scale drawing, depicting the Julian street elevation of the residential building, used as a study of proportions between all of facade’s elements; comparing the ground floor wall and its beam, columns, bays, concrete benches, cast iron gate, window openings, ...
-
The Julian Street Inn - Shelter for the Homeless: Shop Drawing - Window Template
01/01/1988
Architectural Design, Shop Drawing, ElevationDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:Original on VellumSize:42"x56"Scale:1"=1"A full size shop-drawing template, depicting the exterior elevation of the upper segment of a dining hall window.
-
The Julian Street Inn - Shelter for the Homeless: Construction Drawings - Structural Clarifications
14/07/1989
Structural Design, Construction Drawings, Floor Plan, Section, Elevation, DetailsMedium:SepiaSize:24"x43"Scale:1/4"=1'Three drawings depicting the structural improvements for earthquake resistance, and the exterior wall facade treatment of the southwest and northwest corner for the old existing brick building. They include 1) Floor plan and elevations; 2) Roof plan and section; 3) ...
-
The Julian Street Inn - Shelter for the Homeless: Sketches
01/12/1989
Architectural Design, Sketches, ElevationDesigners:Christopher Alexander, Gary Black, James Maguire, Eleni Coromvli, Berkeley, CA, U.S.A.Medium:PhotocopySize:11"x17"Scale:3/4"=1'Four sketches depicting design variations of the iron gate, located on the street facade of the residential building.
-
The Julian Street Inn - Shelter for the Homeless: Structural Design Clarification - Exterior Staircase
01/12/1989
Structural Design, Construction Drawings, Floor Plan, Section, Elevation, DetailsMedium:Original on VellumSize:24"x43"Scale:1/8"=1', 1/2"=1', 3"=1'Structural approved drawing with a revised design and explanatory details for the East exterior staircase, replacing the corresponding permit drawing. It includes first and second floor plans, framing plan, elevations, detailed section of stair roof and building wall connection, and ...
-
The Julian Street Inn - Shelter for the Homeless: Construction Drawings - Landscape
20/12/1989
Landscape Design, Construction Drawings, Planting Plan, Irrigation Plan, DetailsMedium:BlueprintSize:24"x43"Scale:1/2"=1', 1/8"=1'Four landscape design drawings which include: 1) Planting plan with hardscape information, plant list and general notes; 2) Irrigation plan with legend and notes; 3) Irrigation details; Planting details.
SEE ALL Drawings
-
The Julian Street Inn - Shelter for the Homeless: Contract between Housing for Independent People Inc. and the Center for Environmental Structure
14/08/1986
Contractual, Design Services AgreementAuthors:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.
Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.12-page signed design services contract between the Housing for Independent People Inc. and the Center for Environmental Structure as the architect. Work required by the architect includes the preparation of a site plan, preliminary design, working drawings, bid negotiation, supervision, ... -
The Julian Street Inn - Shelter for the Homeless: Exhibit A- FY 1985-86 Working Agreement
01/01/1986
Reference Document27-page reference report describing the primary task, services to be provided and the intents, regarding a homeless project about to be implemented by the San Jose Urban Ministry. A thorough analysis of the problems needs and descriptions of the homeless ...
-
The Julian Street Inn - Shelter for the Homeless: Structural Engineering Contract
27/03/1987
Contractual, Design Services AgreementAuthors:A. J. Miller, A. J. Miller and Associates, Berkeley, CA, U.S.A.
Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.
Al DiLudovio, Housing for Independent People Inc., San Jose, CA, U.S.A.5-page signed contract between the Center for Environmental Structure and A.J. Miller and Associates for providing structural engineering services for the 15,000 square feet building designed by the C.E.S.; co-signed by Housing for Independent People, Inc. -
The Julian Street Inn - Shelter for the Homeless: Energy Compliance Report - San Jose Shelter for the Homeless
08/07/1987
Engineering Report, Energy ReportAuthors:Maxwell Beaumont, Beaumont + Associates, Oakland, CA, U.S.A.Includes information such as Building Envelope Design, Heating and Cooling Summary, Glazing Surface Data, Proposed Construction Assembly, Mandatory Features and Devices Checklist.
-
The Julian Street Inn - Shelter for the Homeless: Standard Form of Agreement Between the Owner and the Contractor
19/11/1987
Contractual, Construction ContractAuthors:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.
Steven H. Oliver, Oliver & Company, Berkeley, CA, U.S.A.
Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.25-page standard AIA agreement form between the Housing for Independent People and Oliver & Company as Contractor with the Center for Environmental Structure as the architect. Establishing the general conditions of the contract, its requirements, duties and timing for initiating ... -
The Julian Street Inn - Shelter for the Homeless: HIP Project - Dinning Hall Truss
09/12/1987
Engineering Report, StructuralAuthors:A. J. Miller, A. J. Miller and Associates, Berkeley, CA, U.S.A.
Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.42-page report on the truss design regarding Down loads, Live loads, Wind loads and Earthquakes. An analytical computer re-run of the nodes for the final truss design are incorporated in the report. -
The Julian Street Inn - Shelter for the Homeless: HIP Project - Shear Walls
10/12/1987
Engineering Report, StructuralAuthors:A. J. Miller, A. J. Miller and Associates, Berkeley, CA, U.S.A.7-page structural study of the dining hall’s periferal shear walls.
-
The Julian Street Inn - Shelter for the Homeless: Torsion Strength of Heat Bent Joints in #10 Reinforcing Bars
01/01/1988
Engineering Report, Structural ReportAuthors:Gary Black, James McGuire, Center for Environmental Structure, Berkeley, CA, U.S.A.Test report on steel details in the concrete truss; it includes Disclaimer, Abstract, 1. Introduction, 2. Testing Procedure, 3. Results and 4. Recommendations for Field Fabrication.
-
The Julian Street Inn - Shelter for the Homeless: Compression Test Results
06/06/1988
Engineering Report, Structural ReportAuthors:Denny Zucchi, Testing and Controls, Mountain View, CA, U.S.A.3 pages with the results of compression tests of the columns and beams of the residential building. Tests were run at the section lines A, B & C, from lines 9 to 21 on 26-Apr-88, 16-May-88, 1-Jun-88 and 22-Jun-88.
-
The Julian Street Inn - Shelter for the Homeless: Architect's Report Regarding General Contractor's Claims for Delay Time
05/05/1989
Project ReportAuthors:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.49-page architect’s report on “General Contractor’s Claims for Delay Time” with a forwarding letter. It includes Table of Contents, Introduction and Outline, Part 1: The Deeep Financial Reasons for Oliver’s Attempt to Discredit C.E.S.; Part 2: Oliver’s Laxed Attitude towards ...
-
The Julian Street Inn - Shelter for the Homeless: Project Close-out Agreement
15/07/1990
Contractual, Close-out AgreementAuthors:Al DiLudovico, Housing for Independent People Inc., San Jose, CA, U.S.A.
Steven H. Oliver, Oliver & Company, Berkeley, CA, U.S.A.
Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.52 pages in total of which eleven pages describe the close-out agreement between Oliver & Company, the Housing for Independent People (HIP) and the Center for Environmental Structure (C.E.S.). The agreement describes and includes six more supportive documents: 1) The ...
SEE ALL Reports
-
The Julian Street Inn - Shelter for the Homeless: Facilities Need Descriptions
28/07/1986
Design Matters, Design StandardsAuthors:Christopher Alexander, Center for Environmental Structure, San Jose, CA, U.S.A.3-page design brief of program area requirements of Julian Street Inn.
-
The Julian Street Inn - Shelter for the Homeless: Contract Specifications
01/01/1986
Design Matters, SpecificationsTwo drafts of specifications organized by divisions and sections; the first 6-page draft includes nine divisions on general requirements, siteworks, materials, installation information etc., and the second 9-page draft continues with Division 9 – Finishes and concludes with Division ...
-
The Julian Street Inn - Shelter for the Homeless: C.E.S. design services progress bills
05/10/1986
Financial, Services FeeAuthors:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Progress bill for Preliminary design, dated 5-Oct-86 with a forwarding letter and a draft including annotations for expected payment dates. .
-
The Julian Street Inn - Shelter for the Homeless: Special Inspection and Testing
01/01/1986
Administrative, Building Permit4-page official document with information about building permit requirements and guidelines when special inspection and testing are demanded. Application form with relevant appendix are included.
-
The Julian Street Inn - Shelter for the Homeless: C.E.S. design services progress bills
05/01/1986
Financial, Services FeeAuthors:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Two progress bills for the commencement of working drawings, dated 5-Jan-86 and 15-Feb-86 respectively. The second bill includes a handwritten correction of the second figure.
-
The Julian Street Inn - Shelter for the Homeless: Notes
01/01/1987
Design Matters, Outstanding IssuesAuthors:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Five pages with notes about functional aspects and physical location, both needed to be addressed in the design of the buildings.
-
The Julian Street Inn - Shelter for the Homeless: Cost estimate and area tabulation by C.E.S.
01/01/1987
Financial, Cost EstimateAuthors:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.22 pages with area tabulation, cost estimate summary of the whole project and cost estimate sheets with notes on construction, quantities, and unit prices; sketches on front sheet, notes and updates throughout.
-
The Julian Street Inn - Shelter for the Homeless: Contract Specifications - Change Order Form
17/08/1987
Design Matters, SpecificationsAuthors:Christopher Alexander, Gary Black, James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.22 pages of edited Contract Specifications with changes requested by owner; the changes refer to the following eleven Divisions: Division 1 – General Requirements; Division 2 – Sitework; Division 3 – Concrete; Division 4 – Masonry; Division 5 – Miscellaneous ...
-
The Julian Street Inn - Shelter for the Homeless: Specifications
01/01/1987
Design Matters, SpecificationsAuthors:Christopher Alexander, Gary Black, James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.19 pages defining the work to be done by the architect in connection to the set of drawings already supplied. It includes the following specifications: 1) Excavation and sitework; 2) Foundations and slabs; 3) Precast panels; 4) Columns and beams; ...
-
The Julian Street Inn - Shelter for the Homeless: Specifications
03/12/1987
Design Matters, SpecificationsAuthors:Christopher Alexander, Gary Black, James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.Architect’s modified specifications to include owner’s concerns; they refer to the following twelve Divisions: General Requirements, Sitework, Concrete, Masonry, Metals, Wood, Moisture and Thermal Protection, Windows, Doors and Glass, Finishes, Plumbing, Electrical, Heating and Ventilation, Allowances and Subcontracts. A draft ...
-
The Julian Street Inn - Shelter for the Homeless: List of Approved Backflow Prevention Assemblies
09/03/1987
Design MattersA list of approved assemblies for reducing water pressure and eliminating water backflow; listed by Company, Model Size, and Status of Approval for each.
-
The Julian Street Inn - Shelter for the Homeless: Private Fire Protection Service
01/01/1987
Design Matters, Design StandardsDocument providing general information on fire protection services and the existing requirements and specifications for the water use.
-
The Julian Street Inn - Shelter for the Homeless: Cost estimates by the Oliver & Co.
31/07/1987
Financial, Cost EstimateAuthors:Maxim D. Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Five studies with contractor’s estimated costs by trade for the whole project, including progressively updated calculations between the months of January and July. Handwritten notes and editing are included.
-
The Julian Street Inn - Shelter for the Homeless: Change orders issued by C.E.S.
09/12/1987
Construction Works, Change OrderAuthors:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Two change orders issued by C.E.S.; the first regards the finished level of the dining hall slab, and the second the connection of the storm drain lateral.
-
The Julian Street Inn - Shelter for the Homeless: Acoustical Analysis of the 50 Unit Attached Residential Project in the City of San Jose
23/11/1987
Design Matters, Design Standards5-page analysis of the noise sources contributing to the existing noise environment of the project site and proposing basic ways to address it. Included is a 10-page extract of a reference document relating to construction specifications of different partitions and ...
-
The Julian Street Inn - Shelter for the Homeless: Invoices issued to C.E.S.
11/05/1987
Financial, Transaction DocumentInvoice statement for the site drainage study, drainage calculations and plan.
-
The Julian Street Inn - Shelter for the Homeless: C.E.S. design services progress bills
22/09/1987
Financial, Services FeeAuthors:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Five progress bills for works already performed. The first dated 15-Feb-87 incorporates the fee increase due to the update on the building cost increase; the second dated 19-Mar-87 includes a corrected fee increase; the third dated 15-Jun-87 includes both a ...
-
The Julian Street Inn - Shelter for the Homeless: Extra C.E.S. work chargeable under Article 9 of contract
22/09/1987
Financial, Services FeeAuthors:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Two-page partial list with design related issues causing the extra charges, which C.E.S. will be evaluating in its future bills.
-
The Julian Street Inn - Shelter for the Homeless: Plan Correction Directive
31/10/1987
Design Matters, Specifications, Outstanding IssuesAuthors:J. Weber, J. LaMar, San Jose Fire Department, San Jose, CA, U.S.A.7-page official report from the Fire Department on the building permit drawings. It provides a 37-point list with detailed comments and guidelines on specifications and items required to be corrected and furnished.
-
The Julian Street Inn - Shelter for the Homeless: PG&E informative note
01/01/1987
Design Matters, NotificationAuthors:Linda M. Carlson, Pacific Gas and Electric Company, San Jose, CA, U.S.A.Information provided by PG&E and refering to the requirements for establishing gas and/or electric service connection to the project on time.
-
The Julian Street Inn - Shelter for the Homeless: Field Order - Storm drain lateral
01/01/1987
Construction Works, Field OrderAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Field Order #4 notifying the general contractor of the required location change of the storm drain lateral; it includes the page of the field order with the description of the changes, and the drawing of the building permit “Plan for ...
-
The Julian Street Inn - Shelter for the Homeless: General Underwriting Requirements for Performance Bonds
01/01/1987
Reference DocumentInsurance agency soliciting clients for writing performance bonds; one page with five bullet points of required information by the contractors .
-
The Julian Street Inn - Shelter for the Homeless. Catalogue cuts on numerous kitchen equipment
03/08/1988
Reference Document59 pages of catalogue cuts for a multitude of kitchen equipment with size information and manufacturers providing them.
-
The Julian Street Inn - Shelter for the Homeless: Answers and clarifications with reference to site meeting on August 4, 1988
04/08/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Four pages with answers on the 20 points raised by the contractor during the August 4th meeting. The given answers relate only to the architectural quality of the building as technical quality is the main responsibility of the contractor.
-
The Julian Street Inn - Shelter for the Homeless: Subcontract drafts
18/02/1988
Construction Works, Subcontracting ServicesAuthors:Christopher Alexander, Gary Black, James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.Two draft subcontracts, one page each; the first refers to “Terracotta tile slab inserts” and the second to “Arcade beams, wood columns and ceilings” .
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for residential building - Walls
15/08/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Four construction clarifications: 1) Specifies the exact wall placement of the two passageways; 2) Specifies the size and placement of the day room street wall; 3 & 4) Specify the second floor’s exterior wall sheathing and nailing spacing.
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for residential building - Heavy beams
18/11/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Four construction clarifications specifying: 1) The anchoring of an 8″x12″ heavy beam to the second floor concrete beam; 2) The ledger beam size and placement; 3) The new connection detail of the 6″x12″ beam supporting the arcade roof to the ...
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for residential building - Roof & floor sheathing
15/08/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Two construction clarifications specifying: 1) The changes in the construction of the 2nd story floor decking; 2) The removal of the 2×4 unnecessary blocking between trusses.
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for residential building - Roof attic ventilation & eave details
25/10/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Two construction clarifications specifying: 1) The ventilation of the attic in ten sketches illustrating the specifics of construction and the access points through plans, elevations, sections and calculations; 2) The frieze details of construction for both, the residence building and ...
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications lists
28/11/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Four lists of clarifications containing: 1) Fourteen non-structural clarifications; 2) Eleven architectural revisions chosen out of the sixteen listed; 3) Twenty eight Structural revisions chosen out of the thirty two listed; 4) Contains the list of all the structural revisions ...
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for residential building - Miscellaneous
05/12/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Two clarifications on 1) Modifications focused on specific windows becoming emergency exits, with additional details of durability and waterproofing to be provided; 2) Seismic joints for building being deleted.
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for dining hall - Foundation & slab
30/09/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Two clarifications setting the final finish height of the Dining Hall slab and specifying the position of the masonry wall in relation to the exterior face of the foundation and the reinforcement needed to support that.
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for dining hall - Walls and windows
08/11/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.The first clarification provided information on the layout of the wall concrete blocks and their openings; the second on the window casement and their installation; and the third on the doors and windows of the wall of the entrance to ...
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for dining hall - Concrete terrace & stair railing
11/10/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.The two clarifications provided revised details for the dining hall south terrace and for the exterior stair railings of the building, as illustrated on a key map and relevant dimensoned elevations and details.
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for residential building - Water proofing details
18/11/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.The first clarification deals with flashing details in the connection of concrete columns and beams to stud walls and the second proposes modifications of previous flashing detail as illustrated in sketches.
-
The Julian Street Inn - Shelter for the Homeless: Cost-free Clarifications for entry courtyard
22/09/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Three clarifications focused on the design of the entry courtyard which include: 1) an elevation and a plan of the entry, 2) elevations and details of the entry wall and its openings and 3) a structural connection of the wall ...
-
The Julian Street Inn - Shelter for the Homeless: Totals of payments to date per contract guidelines
14/04/1988
Financial, Payment DueAuthors:Christopher Alexander, Gary Black, James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.Three documents with the same heading, keeping record of the payments made to C.E.S., the first dated 14-Apr-88, the second 07-Jun-88 and the third 20-Sep-88. Each one of them contains a 10-page analysis based on nine project related categories; the ...
-
The Julian Street Inn - Shelter for the Homeless: Cost-Free Clarifications for 2nd floor arcade - Beams & railings
30/11/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Three construction and design clarifications: 1) One page with sketches of specific beams and their new dimensions; 2) Two pages with sketches and dimensions of the 6″x12″ beam’s connection to the wall; 3) Sketches of elevations, plans and sections with ...
-
The Julian Street Inn - Shelter for the Homeless: Contractor's application and certificate for payment
01/10/1988
Financial, Payment DueAuthors:Maxim D. Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Application for payment #7 of construction works completed between 01-Aug-88 and 01-Sept-88, as analyzed in the tables attached to the application.
-
The Julian Street Inn - Shelter for the Homeless: Reports of construction meetings - October 1988
27/10/1988
Administrative, Minutes of MeetingAuthors:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Four reports with minutes of meetings which took place on: 05-Oct-1988, 12-Oct-1988, 19-Oct-1988 & 27-Oct-1988. Describing discussion with issues presented by the owner, the architect and the contractor, setting a schedule to be followed each week and outlining the week’s ...
-
The Julian Street Inn - Shelter for the Homeless: C.E.S. design services progress bills
16/09/1988
Financial, Services FeeAuthors:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Seven progress bills for works already performed, dated 16-Feb-88, 25-Apr-88, 20-May-88, 16-Sep-88 with note “Balance owing on previous bills”, 16-Sep-88, 16-Sep-88 with note “Second sending of bill with explanations”, 16-Nov-88 with note “Summary of current progress bills”. .
-
The Julian Street Inn - Shelter for the Homeless: Reports of construction meetings - June 1988
30/06/1988
Administrative, Minutes of MeetingAuthors:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Report with minutes of the 30-Jun-1988 meeting describing fourteen issues discussed between the owner, the contractor and the plumbing subcontractor. Issues covered are required change orders, schedule revision, construction status, correspondence between the architect and the owner, architect’s drawings with ...
-
The Julian Street Inn - Shelter for the Homeless: Change Orders
21/10/1988
Construction Works, Change OrderAuthors:Maxim D. Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Sixteen pages of change order proposals relating to specific modifications on building materials and their revised costs, time extensions and new subcontracts required; attached to a letter clarifying that the added costs of supervision, layout and foreman time will be ...
-
The Julian Street Inn - Shelter for the Homeless: Reports of construction meetings - December 1988
15/12/1988
Administrative, Minutes of MeetingAuthors:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Two reports with minutes of meetings which took place on 02-Dec-1988 and 15-Dec-1988 outlining the topics discussed by the contractor, the architect and the owner. Issues discussed are applications for payment, change orders received and still needed, sample panel for ...
-
The Julian Street Inn - Shelter for the Homeless: Reports of construction meetings - July 1988
28/07/1988
Administrative, Minutes of MeetingAuthors:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Four reports with minutes of meetings which took place on 07-Jul-1988, 14-Jul-1988, 21-Jul-1988 & 28-Jul-1988. Meetings focused on all issues which needed to be performed towards the completion of construction, as pending change orders, lists of specific construction activities and ...
-
The Julian Street Inn - Shelter for the Homeless: Reports of construction meetings - August 1988
25/08/1988
Administrative, Minutes of MeetingAuthors:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Four reports with minutes of meetings which took place on 04-Aug-1988, 11-Aug-1988, 18-Aug-1988 & 25-Aug-1988. Meetings focused on detailed lists of construction and design issues requiring prompt solutioning by the contractor and the architect, an update on the subcontractors’ activities, ...
-
The Julian Street Inn - Shelter for the Homeless: Reports of construction meetings - September 1988
28/09/1988
Administrative, Minutes of MeetingAuthors:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Four reports with minutes of meetings which took place on 07-Sep-1988, 15-Sep-1988, 23-Sep-1988 & 28-Sep-1988. Meetings focused on specific issues arising as the construction progressed, demanding action, and various economic issues, as payment requests, requisitions, withholdings for defective work etc. ...
-
The Julian Street Inn - Shelter for the Homeless: Reports of construction meetings - November 1988
03/11/1988
Administrative, Minutes of MeetingAuthors:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Report on the 3-Nov-1988 construction meeting. Discussion focused on building and site finishes, preparation of new change order proposals, construction activities to follow, the importance to complete all details for the Residence Hall and obtain temporary Certificate of Occupancy. Dining ...
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for courtyard & 1st floor arcade
20/10/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Four design and structural clarifications on: 1) Passageway arch design with elevations of the three arches and their specifications, ceiling design, sections and details; 2) Exterior staircase of residential building with roof and railing design as shown in a revised ...
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for windows
11/08/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.One clarification with a two page schedule of all the windows of the building. Schedule includes number of windows per design and building, with rough opening sizes .
-
The Julian Street Inn - Shelter for the Homeless: C.E.S. invoices for subcontracting specialty construction works
25/11/1988
Financial, Subcontracting ServicesAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Two invoices relating to C.E.S. subcontracts; the first dated 31-Oct-88 refers to the arcade precast columns and the lobby ceiling, and the second dated 25-Nov-88 includes the breakdown of the tilework. The third record is an estimate of the total ...
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for 1st floor arcade - Beams
04/10/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Three clarifications focused on the construction of the arcade beams and their various connections and supports: 1) 6″x12″ beam connection at the lobby end of the arcade; 2) 6″x6″ rafter connection to the 6″x12″ beam; 3) All beams of the ...
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for kitchen & showers - Foundation & stud wall finish
30/09/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Two clarifications regarding the construction of walls for the kitchen building: The first includes construction drawings consisting of detailed sections of the various wall to foundation connections throughout the building, key floor plans and one elevation with door and window ...
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for kitchen & showers - General issues
30/09/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Four clarifications on general issues like attic ventilation, gas meter box location and design, connection of kitchen wall to the dining hall wall, and installation of electric wiring for a remotely operated entrance door to the shower area.
-
The Julian Street Inn - Shelter for the Homeless: Cost-free clarifications for kitchen & showers - Waterproofing Construction Details
16/11/1988
Construction Works, ClarificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Three clarifications on the shower room walls and floors: The first specifies sheetrock to be used as substrate for the tiles on walls; the second proposes the placement of a single bathroom drain, with accompanying sketches; the third specifies the ...
-
The Julian Street Inn - Shelter for the Homeless: Job estimate summary; section referring to Dining Hall
11/04/1988
Financial, Cost EstimateTwo pages from the job estimate summary which include the contractor’s estimated costs for all lumber and lumber related material for the dining hall. .
-
The Julian Street Inn - Shelter for the Homeless: Job estimate summary; section referring to 2nd Floor Arcade
11/04/1988
Financial, Cost EstimateTwo pages from the job estimate summary which include the contractor’s estimated costs for all lumber and lumber related material for the 2nd floor arcade; a third page in a version of the first.
-
The Julian Street Inn - Shelter for the Homeless: Job estimate summary; section referring to Arcade Canopy
11/04/1988
Financial, Cost EstimateTwo pages from the job estimate summary which include the contractor’s estimated costs for all lumber and lumber related material for the 2nd floor arcade canopy; a third page in a version of the first.
-
The Julian Street Inn - Shelter for the Homeless: Job estimate summary; section referring to Roof
11/04/1988
Financial, Cost EstimateTwo pages from the job estimate summary which include the contractor’s estimated costs for all lumber and lumber related material for the roof.
-
The Julian Street Inn - Shelter for the Homeless: List of change orders
20/12/1988
Construction Works, Change OrderAuthors:Henry Sterngold, Oliver & Company Inc., Berkeley, CA, U.S.A.Three pages under the title “Change Orders Submitted by Oliver & Company – Analysis” with detailed descriptions of the fourteen submitted change orders and the various items included in each one.
-
The Julian Street Inn - Shelter for the Homeless: Change Order #4 issued by C.E.S.
08/04/1988
Construction Works, Change OrderAuthors:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Change order #4 responding positively to Oliver & Company request to reflect the increased cost of the C.E.S. bond.
-
The Julian Street Inn - Shelter for the Homeless: Change Orders #18 and #18a issued by Oliver & Co.
09/09/1988
Construction Works, Change OrderAuthors:Maxim D. Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Two change orders regarding plumbing works, each describing items to be installed and relative costs.
-
The Julian Street Inn - Shelter for the Homeless: Change Orders #22 and #8rev issued by Oliver & Co.
20/12/1988
Construction Works, Change OrderAuthors:Steven D. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Two change orders referring to the dining hall; the first on raising wall height in accordance with drawings, and the second on roofing specifications.
-
The Julian Street Inn - Shelter for the Homeless: Change Order #2 issued by C.E.S.
25/03/1988
Construction Works, Change OrderAuthors:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Change order #2 referring to the relocation of the residential building explaining how the resulting reduction of square feet affects the previously calculated costs of specific construction items; there is also an earlier version of change order #2.
-
The Julian Street Inn - Shelter for the Homeless: Change Orders # 16, 16a and 16b issued by Oliver & Co.
14/12/1988
Construction Works, Change OrderAuthors:Maxim D. Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Three change orders addressing adjustments to specific finishing elements; #16 and 16a refer to the doors and windows of the residential building, and #16b to lowering the courtyard elevation among other smaller changes.
-
The Julian Street Inn - Shelter for the Homeless: Change Order #5 issued by Oliver & Co.
09/09/1988
Construction Works, Change OrderAuthors:Maxim D. Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Change order #5 refers to changing aluminum to wood-sash windows.
-
The Julian Street Inn - Shelter for the Homeless: Change Order #3 issued by C.E.S.
25/03/1988
Construction Works, Change OrderAuthors:Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Change order #3 regards the modification of the waterproffing detail at the meeting edge between the slab and the exterior wall of the residential building, as indicated in the attached sketch.
-
The Julian Street Inn - Shelter for the Homeless: Change Orders # 17, 17a and 17b issued by Oliver & Co.
06/12/1988
Construction Works, Change OrderAuthors:Maxim D. Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.Three change orders addressing the electrical installations, relocations and additions of specific items for the dining hall the kitchen and the residential building .
-
The Julian Street Inn - Shelter for the Homeless: Change Orders # 15, 21 and 24 issued by Oliver & Co.
14/12/1988
Construction Works, Change OrderAuthors:Steven D. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Three change orders addressing site plumbing matters, utility connections and storm drain installation in accordance to revised drawings and specifications by the City of San Jose.
-
The Julian Street Inn - Shelter for the Homeless: Change Orders #20, #23 and 23A issued by Oliver & Co.
20/12/1988
Construction Works, Change OrderAuthors:Steven D. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Three change orders of various matters related to the residential building; the first on lowering passageway windows to accommodate ceiling; the second on furnishing and installing 2nd floor gutter and down spouts; and the third on installing sheet metal for ...
-
The Julian Street Inn - Shelter for the Homeless: Change Orders # 14, 14a, 14b and 14c issued by Oliver & Co.
20/12/1988
Construction Works, Change OrderAuthors:Steven D. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Four change orders referring to specific number of clarifications provided by C.E.S. and the related costs for adjusting construction details and materials.
-
The Julian Street Inn - Shelter for the Homeless: Meeting notes - Agenda
29/08/1988
Administrative, Minutes of MeetingAuthors:James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.Seven pages with hardwritten notes regarding meetings between C.E.S., the client and the general contractor and issues to be addressed and clarified; they were recorded during five different dates during August 1988; one more typed page with the agenda of ...
-
The Julian Street Inn - Shelter for the Homeless: Notes on billed amounts
14/11/1988
Financial, NotesAuthors:Christopher Alexander, James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.Notes include a handwritten list of payments made to C.E.S. by the HIP, billed between 13-Aug-86 and 14-Nov-88; two more handwritten lists on amounts billed with reference to fees, reimbursements, model, etc.
-
The Julian Street Inn - Shelter for the Homeless: Billing
08/04/1988
Financial, NotesAuthors:James Maguire, Center for Environmental Structure, Berkeley, CA, U.S.A.Handwritten page listing the costs of construction activities, materials, and including general conditions, labor fringes, contingency amount, bond, overhead and fees costs, all summing up to the total contract amount .
-
The Julian Street Inn - Shelter for the Homeless: C.E.S. expenses
09/09/1988
Financial, NotesAuthors:Marian Wattman Oshima, Center for Environmental Structure, Berkeley, CA, U.S.A.Five pages with handwritten notes recording various office expenses by C.E.S. between February and September 1988. The expenses relate to telephone and courier mailing bills, gas, mock-up materials etc.
-
The Julian Street Inn - Shelter for the Homeless: Contractor's application and certificate for payment
31/12/1988
Financial, Payment DueAuthors:Steven D. Oliver, Oliver & Company Inc., Berkeley, CA, U.S.A.Eight applications for payment of construction works completed, as analyzed in the tables attached to the application; the first #2 covers the period from 01-Nov-87 to 11-Apr-88, the second #1 starts on 22-Mar-88, the third #5 covers the period from ...
-
The Julian Street Inn - Shelter for the Homeless: Contractor's application and certificate for payment
09/05/1988
Financial, Payment DueAuthors:Maxim D. Schrogin, Oliver & Company Inc., Berkeley, CA, U.S.A.
Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Application for payment #3 of construction works completed between 11-Apr-88 and 01-May-88, as analyzed in the tables attached to the application. The contractor’s application was certified by C.E.S. following edits of calculations and forwarded to HIP; forwarding letter has been ... -
The Julian Street Inn - Shelter for the Homeless: Invoices issued to Oliver & Co.
25/04/1988
Financial, Transaction DocumentAuthors:Henry Sterngold, Housing for Independent People Inc., San Jose, CA, U.S.A.Invoice of services including reviews of drawings, specifications, contracts, schedule of values, advisory meetings and miscellaneous costs.
-
The Julian Street Inn - Shelter for the Homeless: Invoices issued to Oliver & Co.
01/08/1988
Financial, Transaction DocumentAuthors:Clyde Lawler, Lawler and Stanz Inc, Fairfield, CA, U.S.A.Two invoices by Lawler & Stanz Inc. issued to Oliver & Co. regarding work and material costs for changing PVC to cast iron pipes as required by the San Jose Building Department.
-
The Julian Street Inn - Shelter for the Homeless: Quotation for electrical works
25/07/1988
Financial, Cost EstimateAuthors:John F. Casey, Allied Electric Company, San Jose, CA, U.S.A.Two quotations for electrical works; the first refers to the electrical wiring for the kitchen area with all related fixtures and equipment, and the second to the installation of street light poles and fixtures, including all related works.
-
The Julian Street Inn - Shelter for the Homeless: Subcontractor's cost update
02/08/1988
Financial, Cost EstimateAuthors:Mitchel J. Portera, Metro Plumbing, San Jose, CA, U.S.A.Analysis of costs for installing a larger grease interceptor instead of the one initially approved .
-
The Julian Street Inn - Shelter for the Homeless: C.E.S. design services progress bills
20/05/1988
Financial, Services FeeAuthors:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Four progress bills dated on 16-Feb-88, 4-Apr-88, 25-Apr-88 and 20-May-88 respectively. The 25-Apr-88 is a corrected bill and is accompanied by forwarding letter; a forwarding letters is also attached the 4-Apr-1988 bill.
-
The Julian Street Inn - Shelter for the Homeless: Minor Street Improvement Permit
05/04/1988
Administrative, Building PermitAuthors:Kent Dewel, City of San Jose, Department of Public Works, San Jose, CA, U.S.A.Request by the City of San Jose to the contractor to apply for a Minor Street Improvement Permit, in order to secure street restorations in parallel with the completion of the project. Attachments include: A partially filled-out form to be ...
-
The Julian Street Inn - Shelter for the Homeless: Plan Correction Directive
31/08/1988
Design Matters, Specifications, Outstanding IssuesAuthors:J. Weber, J. LaMar, San Jose Fire Department, San Jose, CA, U.S.A.3-page official report from the Fire Department after reviewing the building permit drawings of the kitchen building only, providing a detailed list and guidelines of all specifications and items required to be corrected and furnished; the inspection card is included ...
-
The Julian Street Inn - Shelter for the Homeless: Door schedule
01/08/1988
Design Matters, SpecificationsAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.3-pages door schedule, including door location drawing, description, size, quantity, and hardware type with remarks; sketches provided for some of them.
-
The Julian Street Inn - Shelter for the Homeless: Window quotation
10/05/1988
Financial, Cost EstimateAuthors:Bill Graham, Truitt and White Lumber Co., Berkeley, CA, U.S.A.2-page quotation for eight window types, based on standard sizes; sketches indicate divisions and opening directions.
-
The Julian Street Inn - Shelter for the Homeless: Window cost estimate
22/08/1988
Financial, Cost EstimateAuthors:Mark Pence, Truitt and White Lumber Co., Berkeley, CA, U.S.A.4-page cost estimate for the windows with detailed information and specifications for each item; estimated total $29,410.75. A draft of the same is also included.
-
The Julian Street Inn - Shelter for the Homeless: Window revised cost estimate
23/08/1988
Financial, Cost EstimateAuthors:Mark Pence, Truitt and White Lumber Co., Berkeley, CA, U.S.A.2-page revised cost estimate of the building windows, with estimated total $25,093.21.
-
The Julian Street Inn - Shelter for the Homeless: Door hardware
10/11/1988
Design Matters, SpecificationsAuthors:Jon Fix, Jackson's Hardware Inc., San Rafael, CA, U.S.A.5-page analysis of door hardware required for each door and pair of doors, including description, quantity and manufacturer.
-
The Julian Street Inn - Shelter for the Homeless: Wood roof & floor framing quotation
27/03/1988
Construction Works, Subcontracting ServicesAuthors:Jack Colliau, Hubbard Structures Inc., Redwood City, CA, U.S.A.2-page proposal for cost reduction on furnishing and installing wooden roof and floor framing systems as per C.E.S. plans and specifications; includes notes and exclusions.
-
The Julian Street Inn - Shelter for the Homeless: Notes on assumptions
01/01/1988
Financial, NotesAuthors:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.List of ten bullet points referring to assumptions made by the contractor in estimating the cost of a job with actions to be taken.
-
The Julian Street Inn - Shelter for the Homeless: Schedule of values
16/08/1988
Financial, Cost EstimateAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Two scheludes of values, the first dated 10-Aug-88 and the second 16-Aug-88, both prepared by C.E.S. The first is based on negotiations between C.E.S. and the contractor after careful analysis of actual values and considered fair. The second schedule contains ...
-
The Julian Street Inn - Shelter for the Homeless: C.E.S. application for progress payment for subcontracting specialty construction works
25/03/1988
Financial, Payment DueAuthors:Christopher Alexander, Center for Environmental Structure, Berkeley, CA, U.S.A.Two progress bills addressed to Oliver & Co. for the specialty works C.E.S. had been executing in the project as a subcontractor. The first progress payment is dated 25-Feb-89 and the second 25-Mar-89; both list eight subcontracts, the amount of ...
-
The Julian Street Inn - Shelter for the Homeless: Purchase order by Oliver & Co.
27/12/1988
Financial, Transaction DocumentPurchase order of construction materials needed on the job site for the specialty works to be executed by C.E.S., pertaining to concrete columns, formework inserts, decorative headers, second story tiles, ceiling beams.
-
The Julian Street Inn - Shelter for the Homeless: Field Order - Modification of building layout
01/03/1988
Construction Works, Field OrderAuthors:Christopher Alexander, Gary Black, Center for Environmental Structure, Berkeley, CA, U.S.A.Field Order #6 notifying the general contractor of modifications on the layout of the building; it provided one page with the description of the changes recorded on attached floorplan.
- The Julian Street Inn - Shelter for the Homeless: Field Order - Acoustic quality of exterior doors, windows and interior partitions